The URL can be used to link to this page

21-230 Griffin Structures Amendment #1 for Project Management & Construction Management for the Library Expansion Project1 FIRST AMENDMENT TO AGREEMENT 146 BETWEEN THE CITY OF CUPERTINO AND GRIFFIN STRUCTURES, INC., FOR PROJECT MANAGEMENT & CONSTRUCTION MANAGEMENT FOR THE LIBRARY EXPANSION This First Amendment to Agreement 146 between the City of Cupertino and Griffin Structures, Inc., is by and between the City of Cupertino, a municipal corporation (hereinafter "City") and Griffin Structures, Inc., a Corporation (“Contractor”) whose address is 1 Technology Dr, Bldg I, Suite 829, Irvine, CA 92618, and is made with reference to the following: RECITALS: On October 22, 2020 Agreement 146 (“Agreement”) was entered into by and between City and Contractor for Project Management & Construction Management for the Library Expansion. A. City and Contractor desire to modify the Agreement on the terms and conditions set forth herein. NOW, THEREFORE, it is mutually agreed by and between and undersigned parties as follows: 1. Paragraph 3.1 of the Agreement is modified to read as follows: Term. This Agreement begins on the Effective Date and ends on March 31, 2023, unless terminated earlier as provided herein (“Contract Time”). The City’s appropriate department head or City Manager may extend the Contract Time through a written amendment to this Agreement, provided such extension does not include additional contract funds. Extensions requiring additional contract funds are subject to the City’s purchasing policy. 2. Except as expressly modified herein, all other terms and covenants set forth in the Agreement shall remain the same and shall be in full force and effect. SIGNATURES CONTINUE ON THE FOLLOWING PAGE 2 IN WITNESS WHEREOF, the parties hereto have caused this modification of Agreement to be executed. CITY OF CUPERTINO By Title Date APPROVED AS TO FORM City Attorney ATTEST: City Clerk Date GRIFFIN STRUCTURES, INC. By Title Date EXPENDITURE DISTRIBUTION Item PO Number Expiration Date Amount Original Agreement 2021-215 3/31/2022 $464,000.00 Amendment #1 3/31/2023 Jon Hughes Executive Vice President Feb 8, 2022 Christopher D. Jensen Jim Throop City Manager Feb 9, 2022 Feb 9, 2022 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY 12/21/2021 AssuredPartners Design Professionals Insurance Services,LLC 3697 Mt.Diablo Blvd Suite 230 Lafayette CA 94549 The Certificate Team CertsDesignPro@AssuredPartners.com License#:6003745 Great American Assurance Company 26344 GRIFSTR-01 Oak River Insurance Company 34630GriffinStructuresInc 1 Technology Dr.,Building I Ste.829 Irvine CA 92618 ARCH SPECIALTY INSURANCE COMPANY 21199 PROGRESSIVE INSURANCE COMPANY 2084922745 A X 1,000,000 X 50,000 X Contractual Liab Excluded Included 1,000,000 2,000,000 X Y Y GLP4051198 12/31/2021 12/31/2022 2,000,000 D 1,000,000 X X X X 064097134 12/31/2021 12/31/2022 A X 4,000,000 X Y EXC4051197 12/31/2021Y 12/31/2022 4,000,000 B XYGRWC22239812/31/2021 12/31/2022 1,000,000 1,000,000 1,000,000 C Professional Laibility PDCPP0038501 12/31/2021 12/31/2022 Per Claim Aggregate Limit Deductible $2,000,000 $4,000,000 $25,000 Excess policy is a follow-form to underlying General Liability/Auto Liability/Employers Liability. Re:All Operations as pertains to named insured. The City of Cupertino,its City Council,officers,officials,employees,agents,servants and volunteers are Additional Insured as respects to General Liability as required per written contract or agreement.Insurance coverage includes waiver of subrogation per the attached. 30 Days Notice of Cancellation The City of Cupertino 10300 Torre Ave Cupertino CA 95014 Copyright, ISO Properties, Inc.,2004 CG 20 33 (Ed. 07/04) XS CG 20 33 (Ed. 07 04) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONT RACTORS - AUTOMATIC STATUS WHEN REQUIRED IN CONSTRUCTION AGREEMENT WITH YOU This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART A. SECTION II - WHO IS AN INSURED is amended to include as an Additional Insured any person or organization for whom you are performing operations when you and such person or organization have agreed in writing in a contract or agreement that such person or organization be added as an Additional In- sured on your policy. Such person or or- ganization is an Additional Insured only with respect to liability for "bodily injury," "prop- erty damage" or "personal and advertising in- jury" caused, in whole or in part, by: 1.your acts or omissions; or 2.the acts or omissions of those acting on your behalf; in the performance of your ongoing oper- ations for the Additional Insured. A person's or organization's status as an Ad- ditional Insured under this endorsement ends when your operations for that Additional In- sured are completed. B.With respect to the insurance afforded to these Additional Insureds, the f ollowing addi- tional exclusions apply: This insurance does not apply to: 1."Bodily injury," "property damage" or "per- sonal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural,engineering or surveying services, including: a.the preparing,approving, or failing to prepare or approve, maps, shop drawings,opinions, reports, surveys, field orders, change orders or draw- ings and specifications; or b.supervisory, inspection, architectural or engineering activities. 2."Bodily injury," or "property damage" oc- curring after: a.all work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the Additional Insured(s) at the location of the covered operations has been completed; or b.that portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than an- other contractor or subcontractor en- gaged in performing operations for a principal as a part of the same project. Great American Assurance Company1PMJDZ GLP4051198 GAC 3649CG (Ed. 11/06) XS GAC 3649CG (Ed. 11 06) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARY NON-CONTRIBUTORY INSURANCE ENDORSEMENT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM OWNERS AND CONTRACTORS PROTECTIVE LIABILITY COVERAGE FORM This insurance is primary to any other insurance held by third parties with respect to work performed by you under written contractual agreements with such third parties and any other insurance which may be available to such third parties shall be non-contributory. Great American Assurance Company 1PMJDZ GLP4051198 Endorsement Effective: Policy No.: Insured: WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 99 04 10 C (Ed. 01-19) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT-CALIFORNIA BLANKET BASIS We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) The additional premium for this endorsement shall be calculated by applying a factor of 2% to the total manual premium, with a minimum initial charge of $350, then applying all other pricing factors for the policy to this calculated charge to derive the final cost of this endorsement. This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule Blanket Waiver Person/Organization Blanket Waiver – Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement No.: Premium $ Insurance Company: WC 99 04 10 C Countersigned by ______________________________________ (Ed. 01-19) Job Description All CA Operations Oak River Insurance Company Waiver Premiu m (prior to adjustments) 12/31/2021 GRWC222398 Great American Assurance Company THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART Schedule © Insurance Services Office, Inc., 2008 CG 24 04 (Ed. 05/09) (Page 1 of 1) Name of Person or Organization: Any person or organization for whom or on whose behalf "you" are performing operations when "you" and such person or organization have agreed in writing in a contract or agreement to waive any right of recovery "we" may have against such person or organization. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to paragraph 8. Transfer of Rights of Recovery Against Others to Us of SECTION IV - CONDITIONS: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products-completed operations hazard." This waiver applies only to the person or organization shown in the Schedule above. CG2404(Ed.05/09) 3ROLF\#: GLP4051198 Project Management & Construction Management for the Library Expansion Project 1 of 11 Design Professional Agr (Single) / April 2020 DESIGN PROFESSIONAL SERVICES AGREEMENT (SINGLE) WITH GRIFFIN STRUCTURES, INC. 1. PARTIES This Agreement is made by and between the City of Cupertino, a municipal corporation (“City”), and Griffin Structures, Inc. (“Consultant”), a Corporation for Project Management & Construction Management for the Library Expansion Project (“Project”), and is effective on the last date signed below (“Effective Date”). 2. SERVICES 2.1 Basic Services. Consultant agrees to provide the Basic Services for the Project, which are set forth in detail in the Scope of Services, attached here and incorporated as Exhibit A, and as further specified in Consultant’s written Proposal as approved by City, except for any provision in the Proposal which conflicts or is inconsistent with this Agreement and the Exhibits hereto, or as otherwise expressly rejected by City. Consultant further agrees to carry out its work in compliance with the City’s Shelter In Place and Social Distancing Requirements, attached here and incorporated as Exhibit A-A. 2.2 Additional Services. City may request at any time during the Contract Time that Consultant provide additional services for the Project, which are not already encompassed, expressly or implicitly, in the Agreement, the Scope of Services, or the Proposal (“Additional Services”). Additional Services must be authorized in writing by City and Consultant will not be paid for unauthorized Additional Services rendered. Additional Services are subject to all the provisions applicable to Basic Services, except and only to the extent otherwise specified by City in writing. All references to “Services” in the Agreement include Basic Services and Additional Services, unless otherwise stated in writing. The Services may be divided into separate sequential tasks, as further specified in this Agreement, the Scope of Services, and Consultant’s Proposal. Consultant is solely responsible for its errors and omissions and those of its subconsultants, and must promptly correct them at its sole expense. Consultant must take appropriate measures to avoid or mitigate any delay, liability, and costs resulting from its errors or omissions. 3. TIME OF PERFORMANCE 3.1 Term. This Agreement begins on the Effective Date and ends on March 31, 2022, unless terminated earlier as provided herein (“Contract Time”). The City’s appropriate department head or City Manager may extend the Contract Time through a written amendment to this Agreement, provided such extension does not include additional contract funds. Extensions requiring additional contract funds are subject to the City’s purchasing policy. 3.2 Schedule of Performance. All Services must be provided within the times specified in Exhibit B, Schedule of Performance, attached and incorporated here. Consultant must promptly notify City of any actual or potential delay in providing the Services as scheduled to afford the Parties adequate Project Management & Construction Management for the Library Expansion Project 2 of 11 Design Professional Agr (Single) / April 2020 opportunity to address or mitigate delays. If the Services are divided by tasks, Consultant must begin work on each separate task upon receiving City’s Notice to Proceed (“NTP”), and must complete each task within the time specified in Exhibit B. 3.3 Time is of the essence for the performance of all the Services. Consultant must have sufficient time, resources, and qualified staff to deliver the Services on time. 4. COMPENSATION 4.1 Maximum Compensation. City will pay Consultant for satisfactory performance of the Basic Services and Additional Services, if approved, a cumulative total amount that will be capped so as not to exceed $464,000.00 (“Contract Price”), as specified in Exhibit C, Compensation, attached and incorporated here, subject to and in accordance with the rights of the City to withhold certain amounts as provided in the Performance Guaranty, Exhibit A. The Contract Price includes all expenses and reimbursements and will remain in place even if Consultant’s actual costs exceed the capped amount. No extra work or payment is permitted in excess of the Contract Price. 4.2 Basic Services. City will pay Consultant $414,000.00 (“Lump Sum Price”) for the complete and satisfactory performance of the Basic Services in accordance with Exhibit C, subject to and in accordance with the rights of the City to withhold certain amounts as provided in the Performance Guaranty, Exhibit A. The Lump Sum Price is inclusive of all time and expenses, including, but not limited to, sub-Consultants’ costs, materials, supplies, equipment, travel, taxes, overhead, and profit. If the Basic Services are not fully completed, Consultant will be compensated a percentage of the Lump Sum Price proportionate to the percentage of Basic Services that were completed to City’s reasonable satisfaction. 4.3 Additional Services. City has the discretion, but not the obligation, to authorize Additional Services up to an amount not to exceed $50,000.00 Additional Services provided to City’s reasonable satisfaction will be compensated on a lump sum basis or based on time and expenses, in accordance will the Hourly Rates and Reimbursable Expenses Schedules included in Exhibit C, subject to and in accordance with the rights of the City to withhold certain amounts as provided in the Performance Guaranty, Exhibit A. If paid on an hourly basis, Consultant will be compensated for actual costs only of normal business expenses and overhead, with no markup or surcharge (“Reimbursable Expenses”). Consultant will not be entitled to reimbursement for copying, printing, faxes, telephone charges, employee overtime, or travel to City offices or to the Project site. 4.4 Invoices and Payments. Monthly invoices must describe the Services completed and the Amount due for the preceding month. City will pay Consultant within thirty (30) days following receipt of a properly submitted and approved invoice for Services. However, the City will withhold 10% of each payment to Consultant, excluding any amounts for expense reimbursements, pursuant to the terms of the Performance Guaranty, Exhibit A. The invoice must separately itemize and provide subtotals for Basic Services and Additional Services, and must state the percentage of completion for each task, as specified in Exhibit C. City will notify Consultant in writing of any disagreements with the invoice or the stated percentage of completion of tasks. If the disagreement is unresolved, City will pay Consultant only for the undisputed portion of the Services. Disputed amounts shall be subject to the Dispute Resolution provision of this Agreement. a. Time and Expenses. For Additional Services provided on an hourly basis, each invoice must also include, for each day of Services provided: (i) name and title of each person Project Management & Construction Management for the Library Expansion Project 3 of 11 Design Professional Agr (Single) / April 2020 providing Services; (ii) a succinct summary of the Services performed by each person; (iii) the time spent per person, in thirty (30) minute increments; (iv) the hourly billing rate or Sub- Consultant charge and payment due; and (v) an itemized list with amounts and explanation for all permitted reimbursable expenses. b. Rates and Receipts. All hourly rates and reimbursable expenses must conform to the City- approved rates set forth in Exhibit C, which will be in effect for the entire Contract Time. Each invoice must attach legible, dated receipts for Reimbursable Expenses. 5. INDEPENDENT CONTRACTOR 5.1 Status. Consultant is an independent Consultant and not an employee, partner, or joint venture of the City. Consultant is solely responsible for the means and methods of performing the Services and shall exercise full control over the employment, direction, compensation and discharge of all persons assisting Consultant in performing the Services. Consultant is not entitled to health benefits, worker’s compensation, retirement, or any City benefit. 5.2 Qualifications and Standard of Care. Consultant represents on behalf of itself and its sub- Consultants that they have the qualifications and skills to perform the Services in a competent and professional manner, as exercised by design professionals performing similar services in the S an Francisco Bay Area. Services may only be performed by qualified and experienced personnel or subconsultants who are not employed by City and do not have any contractual relationship with City excepting this Agreement. All Services must be performed as specified to City’s reasonable satisfaction. 5.3 Permits and Licenses. Consultant warrants on behalf of itself and any sub-Consultants that they are properly licensed, registered, and/or certified to perform the Services, as required by law, and that they have procured a valid City Business License, if required by the Cupertino Municipal Code. 5.4 Sub-Consultants. Unless prior written approval from City is obtained, only Consultant’s employees and sub-Consultants whose names are included in this Agreement and incorporated Exhibits may provide Services under this Agreement. Consultant must require all sub-Consultants to furnish proof of insurance for workers’ compensation, commercial liability, auto, and professional liability in reasonable conformity to the insurance required of Consultant. The terms and conditions of this Agreement shall be binding on all sub-Consultants relative to the portion of their work. 5.5 Tools, Materials, and Equipment. Consultant will supply and shall be responsible for all tools, materials, and equipment required to perform the Services under this Agreement. 5.6 Payment of Benefits and Taxes. Consultant is solely responsible for the payment of employment taxes incurred under this Agreement and any similar federal or state taxes. Consultant and any of its employees, agents, and subcontractors shall not have any claim under this Agreement or otherwise against City for seniority, vacation time, vacation pay, sick leave, personal time off, overtime, health insurance, medical care, hospital care, insurance benefits, social security, disability, unemployment, workers compensation or employee benefits of any kind. Consultant shall be solely liable for and obligated to pay directly all applicable taxes, fees, contributions, or charges applicable to Consultant’s business including, but not limited to, federal and state income Project Management & Construction Management for the Library Expansion Project 4 of 11 Design Professional Agr (Single) / April 2020 taxes. City shall have no obligation whatsoever to pay or withhold any taxes or benefits on behalf of Consultant. Should any court, arbitrator, or administrative authority, including but not limited to the California Public Employees Retirement System (PERS), the Internal Revenue Service or the State Employment Development Division, determine that Consultant, or any of its employees, agents, or subcontractors, is an employee for any purpose, then Consultant agrees to a reduction in amounts payable under this Agreement, or to promptly remint to City any payments due by the City as a result of such determination, so that the City’s total expenses under this Agreement are not greater than they would have been had the determination not been made. 5.7 Errors and Omissions. Consultant is solely responsible for its errors and omissions and those of its sub-Consultants, and must take prompt measures to avoid, mitigate, and correct them at its sole expense. 6. PROPRIETARY/CONFIDENTIAL INFORMATION During the Contract Time, Consultant may have access to private or confidential information owned or controlled by the City, which may contain proprietary or confidential details, the disclosure of which to third parties may be damaging to City. Consultant shall hold in confidence all City information and use it only to perform this Agreement. Consultant shall exercise the same standard of care to protect City information as a reasonably prudent Consultant would use to protect its own proprietary data. 7. OWNERSHIP OF MATERIALS 7.1 Property Rights. Subject to City meeting its payment obligations for the Services, any interest (including copyright interests) of Consultant in any product, memoranda, study, report, map, plan, drawing, specification, data, record, document, or other information or work, in any medium, prepared by Consultant under this Agreement (“Work Product”), will be the exclusive property of the City upon completion of the work to be performed hereunder or upon termination of this Agreement, to the extent requested by City. In any case, no Work Product shall be shown to a third-party without prior written approval by City 7.2 Copyright. To the extent permitted by Title 17 of the U.S. Code, all copyrights to the Work Product prepared/created by Consultant and its sub-Consultants and all copyrights in such Work Product shall constitute City property. If it is determined under federal law that the Work Product is not “works for hire,” Consultant hereby assigns to City all copyrights to the Work Product when and as created, and shall require sub-Consultants to do the same. Consultant may retain copyrights to its standard details, but hereby grants City a perpetual, non-exclusive license to use such details. 7.3 Patents and Licenses. Consultant must pay royalties or license fees required for authorized use of any third party intellectual property, including but not limited to patented, trademarked, or copyrighted intellectual property if incorporated into the Services or Work Product of this Agreement. 7.4 Re-Use of Work Product. Unless prohibited by law and without waiving any rights, City may use or modify the Work Product of Consultant and its sub-Consultants to execute or implement any of the following, but Consultant shall not be responsible or liable for City’s re-use of Work Product: (a) For work related to the original Services for which Consultant was hired; (b) To complete the original Services with City personnel, agents or other Consultants; Project Management & Construction Management for the Library Expansion Project 5 of 11 Design Professional Agr (Single) / April 2020 (c) To make subsequent additions to the original Services; and/or (d) For other City projects. 7.5 Deliverables and Format. Electronic and hard copies of the Work Product constitute part of the Deliverables required under this Agreement, which shall be provided to City on recycled paper and copied on both sides, except for one single-sided original. Large-scale architectural plans and similar items must be in CAD and PDF formats, and unless otherwise specified, other documents must be in Microsoft Office applications and PDF formats. 8. RECORDS 8.1 Consultant must maintain complete, accurate, and detailed accounting records relating to the Services and Compensation, in accordance with generally accepted accounting principles and procedures. The records must include detailed information about Consultant’s performance, benchmarks, and deliverables. The records and supporting documents must be kept separate from other files and maintained for a period of four (4) years from the date of City’s final payment. 8.2 Consultant will provide City full access to Consultant’s books and records for review and audit, to make transcripts or copies, and to conduct a preliminary examination of all the work, data, documents, proceedings, and activities related to this Agreement. If a supplemental examination or audit of Consultant’s records discloses non-compliance with appropriate internal financial controls, a contract breach, or a failure to act in good faith, City will be entitled to recover from Consultant the costs of the supplemental examination. If this is a lump sum fee Agreement, City will be provided access to records of reimbursable expenses and the instruments of service/deliverables for review and audit. This Section 8 survives the expiration/termination of this Agreement. 9. ASSIGNMENT Consultant shall not assign, sublease, hypothecate, or transfer this Agreement, or any interest therein, directly or indirectly, by operation of law or otherwise, without prior written consent of City. Any attempt to do so will be null and void. Any changes related to the financial control or business nature of Consultant as a legal entity will be considered an Assignment subject to City approval, which shall not be unreasonably withheld. For purposes of this provision, control means fifty percent (50%) or more of the voting power of the business entity. This Agreement binds Consultant, its heirs, successors and assignees. 10. PUBLICITY / SIGNS Any publicity generated by Consultant for the project under this Agreement, during the term of this Agreement and for one (1) year thereafter, will reference the City’s contributions in making the project possible. The words “City of Cupertino” will be displayed in all pieces of publicity, including flyers, press releases, posters, brochures, public service announcements, interviews, and newspaper articles. No signs may be posted, exhibited, or displayed on or about City property, except signage required by law or this Agreement, without prior written approval from the City. 11. INDEMNIFICATION 11.1 To the fullest extent allowed by law and except for losses caused by the sole or active negligence or willful misconduct of City personnel, Consultant agrees to indemnify, defend, and hold Project Management & Construction Management for the Library Expansion Project 6 of 11 Design Professional Agr (Single) / April 2020 harmless the City as follows: a. Indemnity for Design Professional Liability: With respect to the performance of design professional services by a design professional as defined in California Civil Code Section 2782.8, to the fullest extent permitted by law, Consultant shall indemnify and hold harmless City, its officers, officials, agents, employees, and volunteers (collectively and/or individually “City”) from and against any and all liabilities, claims, damages, losses, costs, or expenses (including, without limitation, costs, attorneys’ fees, and expert fees of litigation and alternative dispute resolution) of every nature to the extent arising out of, pertaining to, or relating to the negligence, recklessness, or willful misconduct of Consultant or any of its officers, employees, serv ants, agents, or subcontractors (collectively and/or individually “Consultant”), in the performance of this Agreement or failure to comply with any obligations of the Agreement. If it is finally determined (through a non-appealable judgment or an agreement between City and Consultant) that liability is caused by the comparative negligence or willful misconduct of City, then Consultant’s indemnification and hold harmless obligation shall not exceed Consultant’s finally determined percentage of liability based upon the comparative fault of Consultant. Irrespective of any language to the contrary in this Agreement, the Consultant has no duty to provide or to immediately pay for an up-front defense of City against unproven claims or allegations, but shall reimburse those litigation costs and expenses (including, without limitation, attorneys’ fees, and expert fees) incurred by the City to the extent caused by the negligence, recklessness, or willful misconduct of Consultant. In no event shall the cost to defend charged to Consultant exceed Consultant’s proportional percentage of fault, except as described in Section 2782.8(a) and (e) of the California Civil Code. b. Claims Involving Intellectual Property. Consultant shall indemnify, defend, and hold harmless Indemnitees from and against any claim involving intellectual property, infringement, or violation of a United States patent right or copyright, trade secret, trademark, or service mark or other proprietary or intellectual property rights, which arises out of, pertains to, or relates to Consultant’s negligence, recklessness, or willful misconduct. Such costs and expenses will include reasonable attorney fees for legal counsel of City’s choice, expert fees, and all other costs and fees of litigation. c. Claims for Other Liability. Except as provided in subsections 11.1(a) and (b), to the fullest extent permitted by law, Consultant shall hold harmless, defend (with counsel agreed to by City), and indemnify City and its officers, officials, agents, employees, and volunteers (collectively and/or individually “City”) from and against any and all liability, claim, loss, damage, expense, costs (including, without limitation, costs, attorneys’ fees, and expert fees of litigation) of every nature arising out of, related to, or in connection with the performance of work hereunder by Consultant or any of its officers, employees, servants, agents, or subcontractors, or the failure of the same to comply with any of the obligations contained in this Agreement, except such loss or damage which was caused by the sole negligence or sole willful misconduct of the City. Consultant’s duty to defend applies immediately, whether or not liability is established. An allegation or determination that persons other than Contractor are responsible for the claim does not relieve Contractor from its separate and distinct obligation to defend as stated herein. 11.2 Consultant will assist City, at no additional cost, in the defense of any claim, dispute, or Project Management & Construction Management for the Library Expansion Project 7 of 11 Design Professional Agr (Single) / April 2020 lawsuit arising out of this Agreement. Consultant’s duties herein are not limited to or subject to the Contract Price, to Workers’ Compensation claims, or to the Insurance or Bond limits and provisions. Nothing in this Agreement shall be construed to give rise to an implied right of indemnity in favor of Consultant against any Indemnitee. 11.3 Consultant agrees to pay the reasonable costs City may incur in enforcing this provision related to Consultant’s indemnification duties, including reasonable attorney fees, fees for legal counsel acceptable to City, expert fees, and all other costs and expenses related to a claim or counterclaim, a purchase order, another transaction, litigation, or dispute resolution. Without waiving any rights, City may deduct money from Consultant’s payments to cover moneys due to City. 11.4 Consultant agrees to obtain executed indemnity agreements with provisions identical to those set forth here in this Section 11 from each and every subcontractor, or any other person or entity involved by, for, with, or on behalf of Consultant in the performance of this Agreement. Failure of City to monitor compliance with these requirements imposes no additional obligations on City and will in no way act as a waiver of any rights hereunder. 11.5 This Section 11 shall survive expiration or termination of this Agreement. 12. INSURANCE On or before the Contract Time commences, Consultant shall furnish City with proof of compliance with City Insurance Requirements, attached and incorporated here as Exhibit D. City will not execute the Agreement until Consultant has submitted and City has reasonably approved receipt of satisfactory certificates of insurance and endorsements evidencing the type, amount, class of operations covered, and the effective and expiration dates of coverage. Alternatively, City may terminate this Agreement or in its sole discretion purchase insurance at Consultant’s expense and deduct costs from payments to Consultant. 13. COMPLIANCE WITH LAWS 13.1 General Laws. Consultant shall comply with all laws and regulations applicable to this Agreement. Consultant will promptly notify City of changes in the law or other conditions that may affect the Project or Consultant’s ability to perform. Consultant is responsible for verifying the employment authorization of employees performing the Services, as required by the Immigration Reform and Control Act, or other federal or state law, rule or regulation. 13.2 Labor Laws. Consultant shall comply with all labor laws applicable to this Agreement. If the Services include a “public works” component, Consultant must comply with prevailing wage laws under Labor Code Section 1720 and other labor laws. To the extent applicable, Consultant must comply with City’s Labor Compliance Program and with state labor laws pertaining to working days, overtime, payroll records and DIR Registration and Oversight. If the Contract Price is $30,000 or more, Consultant must comply with the apprenticeship requirement in Labor Code Section 1777.5. 13.3 Discrimination Laws. Consultant shall not discriminate on the basis of race, religious creed, color, ancestry, national origin, ethnicity, handicap, disability, marital status, pregnancy, age, sex, gender, sexual orientation, gender identity, Acquired-Immune Deficiency Syndrome (AIDS), or any other protected classification. Consultant shall comply with all anti-discrimination laws, including Government Code Section 12900 and 11135, and Labor Code Section. 1735, 1777, and 3077.5. Project Management & Construction Management for the Library Expansion Project 8 of 11 Design Professional Agr (Single) / April 2020 Consistent with City policy prohibiting it, Consultant understands that harassment and discrimination by Consultant or any of its sub-Consultants toward a job applicant, an employee, a City employee, or any other person is strictly prohibited. 13.4 Conflicts of Interest. Consultant shall comply with all conflict of interest laws and regulations applicable to this Agreement and must avoid any conflict of interest. Consultant warrants that no public official, employee, or member of a City board or commission who might have been involved in the making of this Agreement, has or will receive a direct or indirect financial interest in this Agreement in violation of California Government Code Section 1090 et seq. Consultant may be required to file a conflict of interest form if Consultant makes certain governmental decisions or serves in a staff capacity, as provided in Section 18700 of Title 2 of the California Code of Regulations and other laws. Services may only be performed by persons who are not employed by City and who do not have any contractual relationship with City, with the exception of this Agreement. Consultant is familiar with and agrees to abide by the City’s rules governing gifts to public officials and employees. 13.5 Remedies. A violation of this Section 13 constitutes a material breach and may result in City suspending payments, requiring reimbursement, or terminating this Agreement. City reserves all its rights and remedies under law and this Agreement, including the right to seek indemnification under Section 11. Consultant agrees to indemnify, defend, and hold City harmless from and against any loss, liability, and expenses arising from noncompliance with this Section. 14. PROJECT COORDINATION 14.1 City Project Manager. The City’s Project Manager for all purposes under this Agreement will be Roger Lee, who shall have the authority to manage this Agreement and oversee the progress and performance of the Services. City in its sole discretion may substitute another Project Manager at any time and will advise Consultant of the new representative. 14.2 Consultant Project Manager. Subject to City’s reasonable approval, Consultant’s Project Manager for all purposes under this Agreement will be Jon Hughes, who shall be the single representative for Consultant with the authority to manage compliance with this Agreement and oversee the progress and performance of the Services. This includes responsibility for coordinating and scheduling the Services in accordance with City instructions, service orders, and the Schedule of Performance, and providing regular updates to the City’s Project Manager on the Project status, progress, and any delays. City written approval is required prior to Consultant substituting a new Project Manager, which shall result in no additional costs to City or Project delays. 15. ABANDONMENT OF PROJECT City may abandon or postpone the Project with thirty (30) calendar days written notice to Consultant. Consultant will be compensated for satisfactory Services performed through the date of abandonment and will be given reasonable time to assemble the work and close out the Services. No close out work shall be conducted without City reasonable approval of closure costs, which may not exceed ten percent (10%) of the total time expended to the date of abandonment. All charges including job closure costs will be paid in accordance with the provisions of this Agreement and within thirty (30) days of Consultant’s final invoice reasonably approved by the City. Project Management & Construction Management for the Library Expansion Project 9 of 11 Design Professional Agr (Single) / April 2020 16. TERMINATION City may terminate this Agreement for cause or without cause at any time, following reasonable written notice to Consultant at least thirty (30) calendar days prior to the termination date. Consultant will be paid for satisfactory Services rendered through the date of termination, but final payment will not be made until Consultant closes out the Services and delivers all Work Product to City. All charges approved by City including job closure costs will be paid within thirty (30) days of Consultant’s final invoice. 17. GOVERNING LAW, VENUE, AND DISPUTE RESOLUTION This Agreement is governed by the laws of the State of California, excepting any choice of law rules which may direct the application of laws of another jurisdiction. Any lawsuits filed related to this Agreement must be filed with the Superior Court for the County of Santa Clara, State of California. Consultant must comply with the claims filing requirements under the Government Code prior to filing a civil action in court against City. The Agreement and obligations of the parties are subject to all valid laws, orders, rules, and regulations of the authorities having jurisdiction over this Agreement (or the successors of those authorities). If a dispute arises, Consultant must continue to provide the Services pending resolution of the dispute. If the Parties elect arbitration, the arbitrator’s award must be supported by law and substantial evidence and include detailed written findings of law and fact. 18. ATTORNEY FEES If City initiates legal action, files a complaint or cross-complaint, or pursues arbitration, appeal or other proceedings to enforce its rights or a judgment in connection with this Agreement, the prevailing party will be entitled to reasonable attorney fees and costs. This Section 18 survives the expiration/termination of this Agreement. 19. THIRD PARTY BENEFICIARIES There are no intended third party beneficiaries of this Agreement. 20. WAIVER Neither acceptance of the Services nor payment thereof shall constitute a waiver of any contract provision. City’s waiver of any breach shall not be deemed to constitute waiver of another term, provision, covenant, or condition or a subsequent breach, whether of the same or a different character 21. ENTIRE AGREEMENT This Agreement represents the full and complete understanding of the Parties, of every kind or nature, and supersedes any and all other agreements and understandings, either oral or written, between them. Any modification of this Agreement will be effective only if in writing and signed by each Party’s authorized representative. No verbal agreement or implied covenant will be valid to amend or abridge this Agreement. If there is any inconsistency between any term, clause, or provision of this main Agreement and any term, clause, or provision of the attachments or exhibits thereto, the terms of the main Agreement shall prevail and be controlling. Project Management & Construction Management for the Library Expansion Project 10 of 11 Design Professional Agr (Single) / April 2020 22. INSERTED PROVISIONS Each contractual provision or clause that may be required by law is deemed to be included and will be inferred in this Agreement. Either party may request an amendment to cure any mistaken insertion or omission of a required provision. 23. HEADINGS The headings in this Agreement are for convenience only, are not a part of the Agreement and in no way affect, limit, or amplify the terms or provisions of this Agreement. 24. SEVERABILITY/PARTIAL INVALIDITY If any term or provision of this Agreement, or their application to a particular situation, is found by the court to be void, invalid, illegal or unenforceable, such term or provision shall remain in force and effect to the extent allowed by such ruling. All other terms and provisions of this Agreement or their application to specific situations shall remain in full force and effect. 25. SURVIVAL All provisions which by their nature must continue after the Agreement ends, including without limitation those referenced in specific Sections herein, survive this Agreement and shall remain in full force and effect. 26. NOTICES All notices, requests, and approvals must be sent to the persons below in writing to the persons below, and will be considered effective on the date of personal delivery, the delivery date confirmed by a reputable overnight delivery service, on the fifth calendar day after deposit in the United States Mail, postage prepaid, registered or certified, or the next business day following electronic submission: To City of Cupertino: 10300 Torre Ave. Cupertino CA 95014 Attention: Roger Lee Email: rogerl@cupertino.org To Consultant: Griffin Structures, Inc. 2 Technology Dr, Suite 150, Irvine, CA 92618 Attention: Jon Hughes Email: jhughes@griffinstructures.com 27. VALIDITY OF CONTRACT This Agreement is valid and enforceable only if it complies with the contract provisions of Cupertino Municipal Code Chapters 3.22 and 3.23, is signed by the City Manager or authorized designee, and is approved for form by the City Attorney’s Office. Project Management & Construction Management for the Library Expansion Project 11 of 11 Design Professional Agr (Single) / April 2020 28. EXECUTION The person executing this Agreement on behalf of Consultant represents and warrants that Consultant has the right, power, and authority to enter into this Agreement and carry out all actions herein, and that he or she is authorized to execute this Agreement, which constitutes a legally binding obligation of Consultant. This Agreement may be executed in counterparts, each one of which is deemed an original and all of which, taken together, constitute a single binding instrument. IN WITNESS WHEREOF, the parties have caused the Agreement to be executed on the Effective Date stated earlier in this Agreement. CITY OF CUPERTINO GRIFFIN STRUCTURES, INC A Municipal Corporation By Name Title Date By Name Title Date Tax I.D. No.: 33-0756139 APPROVED AS TO FORM: HEATHER M. MINNER Cupertino City Attorney ATTEST: KIRSTEN SQUARCIA City Clerk Date Jon Hughes Executive Vice President Oct 21, 2020 Jon Hughes Heather M. Minner Deborah L. Feng Oct 22, 2020 City Manager Deborah L. Feng Oct 22, 2020 EXHIBIT A Scope of Services Design Professionals & Consultant Contracts Exh. A-Scope of Services for Design Professionals & Consultant Contracts - Draft 2 1 SCOPE OF SERVICES INCLUDED IN THE RFP: 8/26/2020 The Project management services will start with the review of the Design-Build Entities design and comparing it to the bridging documents and will continue through the completion of the construction phase and building commissioning. Specific services anticipated include but not limited to the following: • Assignment of a Project Manager for the duration of the project. The PM shall have relevant building project management experience with DB experience preferred. The PM will be the City’s primary representative with the design-build firm and the party responsible for administering the construction contract for the City. • Coordination with City staff, library staff and members of the public during construction. Specific work includes coordinating the timing of work, minimizing the impacts to the library, the p arking lot, ingress and egress to the site by the contractor and communicating work plans to interested parties as well as responding to interested parties about the project. • Provide document management • Provide document quality check • Review construction documents for conformance with the bridging documents. • Provide management of the project and the construction manager. • Efficiently mitigate construction document conflicts with the CM. • Plan and assist others in establishing project budgets; track and report on project expenditures; timely communication of deviations from project expenditure plan and propose alternatives to align expenditures with budget. Plan and assist others in establishing project schedules and milestones; prepare, and communic ate schedules and report on progress of project activities; develop critical path or project flow diagrams to plan, set and evaluate progress on project tasks; timely communication of deviations from project schedule and propose alternatives to align project activities with planned schedule. • Manage schedule and ensure timely performance and delivery of project • Oversee compliance with permits, regulations, mitigation measures and other requirements • Perform project management activities which achieve, but are not limited to, planning, establishing, and executing project performance and design objectives, schedules and budgets; regulatory compliance; process and project documentation; reporting the status. • Record Drawing verification. • Coordinate with City Attorney’s Office on the preparation and review of required contract documents. • Prepare project staff reports for City Council, Planning Commission, and other advisory bodies. • Make presentations to the City Council, boards and commissions, and advisory committees and citizen groups Construction Phase: • Administration and coordination of the DBE contract EXHIBIT A Scope of Services Design Professionals & Consultant Contracts Exh. A-Scope of Services for Design Professionals & Consultant Contracts - Draft 2 2 • Schedule meetings and prepare meeting agendas and minutes for all project meetings • Meet weekly with City designated Project Manager to provide an update of the current status of the project and provide summary report. • Monitoring of construction costs and progress payments • Substantial completion/final completion/project closeout • Progress records • Site observations • Reimbursable expense for testing and inspections by subconsultants • Utility coordination Post Construction Phase: • Resolution of project issues • Close out all contracts • Close out binder with as-builts and record drawings DESIGN BUILD APPROACH, SUBMITTED BY GRIFFIN STRUCTURES: 9/09/2020 SEE NEXT PAGE EXHIBIT A Scope of Services Design Professionals & Consultant Contracts Exh. A-Scope of Services for Design Professionals & Consultant Contracts - Draft 2 3 EXHIBIT A Scope of Services Design Professionals & Consultant Contracts Exh. A-Scope of Services for Design Professionals & Consultant Contracts - Draft 2 4 EXHIBIT A Scope of Services Design Professionals & Consultant Contracts Exh. A-Scope of Services for Design Professionals & Consultant Contracts - Draft 2 5 2 Technology Drive, Suite 150, Irvine, CA 92618 Tel: 949 497-9000 Fax: 949 497-8883 GRIFFIN STRUCTURES, INC. PERFORMANCE GUARANTY TO THE CITY OF CUPERTINO Performance-based Retentions Compensation for Griffin Structures, Inc. (“Griffin”) services to the City of Cupertino (“City’) is set forth in the Design Professional Services Contract between Griffin and City (“Contract”), Section 4, incorporated herein by reference, with a Basic Services fee amount not-to-exceed $414,000 and Additional Services of up to $50,000 on an as-requested basis, for a Maximum Compensation of $464,000. Included in the Maximum Compensation amount of $464,000 is $12,425 in reimbursable costs and $60,000 in special testing and inspection. Performance-based retention, as defined below, will only apply to the services directly provided by Griffin in the amount of $341,575 (“Performance-based Amount”) Griffin agrees that ten percent (10%) of the Performance-based Amount shall be retained by City as provided in Section 4.4 of the Contract (“Performance Retention”) and only released to Griffin under the terms as described herein. Upon determination by the City that the library project is 100% complete, the City will determine it in its “sole” discretion what percentage of the Performance Retention, if any, shall be released to Griffin based on the following criteria: 1) 100% of the Performance Retention shall be released and paid to Griffin by City in a lump sum if Griffin’s services are rated by the City in its “sole” discretion, as “Excellent” or “A”; 2) 80% of the Performance Retention shall be released and paid to Griffin by City in a lump sum if Griffin’s services are rated by the City, in its “sole” discretion, as “good” or “B”; 3) 70% of the Performance Retention shall be released and paid to Griffin by City in a lump sum if Griffin’s services are rated by the City, in its “sole” discretion as ‘Fair/Satisfactory” or “C”, and; 4) If Griffin’s services as rated by City, in its “sole” discretion is less than “A” through “C” as identified herein, no release of any Performance Retention to Griffin by the City shall be required or made by the City. AGREED: GRIFFIN STRUCTURES, INC. A California Corporation _______________________ ______________ By: Jon Hughes, EVP Date 10/14/2020 Revised: July 13, 2020 – Public Works Contracts 1 Exhibit A-A – SHELTER IN PLACE AND SOCIAL DISTANCING REQUIREMENTS A. Health Laws Acknowledged. It is acknowledged that Consultant’s/Contractor’s (“Contractor”) duty to comply with Laws, as defined in Section 13 of the Contract/Agreement (“Contract”), includes immediate compliance by Contractor and its subcontractors with the restrictions on travel and the Social Distancing Requirements set forth in the most recent health order issued by the County of Santa Clara Health Department in response to the COVID-19 pandemic, and any subsequent amendments or superseding orders thereto (the “Health Order”), and any other local, state, or federal laws that have been or may be enacted in response to the COVID-19 pandemic (collectively, “Health Laws”). B. Health Order Compliance. Contractor shall comply with any restrictions on travel and social distancing requirements in the Health Order when preforming work under this Contract. If a scope of work item, notice to proceed, or work order under this Contract specifies work that cannot be performed in compliance with the Health Order or other Health Laws, Contractor shall refrain from conducting the work and immediately inform the City. C. Individuals at High Risk of Severe Illness. Nothing in this Contract shall be interpreted to require any person at high risk of severe illness from COVID-19 to leave their residence to perform work under the Contract. Contractor will inform the City if other arrangements for the work must be made, and City will do so, with no penalty to Contractor, although Contractor will not be compensated for work performed by the City or third parties. Information from the Center for Disease Control ("CDC") on "high risk" categories is available at the CDC's website at: https://www.cdc.gov/coronavirus/2019-ncov/specific-groups/people-at-higher-risk.html. D. Health Order Requirements and Best Practices. Contractor will immediately undertake all appropriate measures to ensure compliance with the Social Distancing Requirements in the Health Order by all individuals on any project site or work area performing work under this Contract, including Contractor's or any subcontractor's workers, employees, representatives, vendors, or suppliers (collectively, "workers"), and shall maintain these measures for as long as required by the Health Order or other Health Laws. In particular, Contractor must comply with the provisions of the County’s Mandatory Directive for Construction Projects (attached hereto), as applicable. Further, as long as required by the operative Health Order or Mandatory Directive for Construction Projects, or other Health Laws, these measures shall include, but are not limited to, the following best practices: 1. Information. Inform all workers of the Social Distancing Requirements and these best practices, including any updates or modifications, and require compliance as a condition to being present on the project site or work area. Revised: July 13, 2020 – Public Works Contracts 2 2. Social Distancing Protocol. Fill out and submit the newest version of the Social Distancing Protocol to the County, using the County’s online form available at https://www.sccgov.org/sites/covid19/Pages/social-distancing-protocol.aspx. 3. Sick Workers. Prohibit any individuals who have been tentatively or conclusively diagnosed with COVID-19 or who have any symptoms of illness, including the following, from entering or remaining on the project site or work area: fever, cough, shortness of breath, sore throat, body aches, chills, sudden loss of smell or taste or other flu-like symptoms. Encourage sick workers to get immediate medical attention. 4. Signage/Posters. As required, post or distribute (1) the most updated version of the COVID-19 PREPARED Sign, and (2) a Social Distancing Protocol Visitor Information Sheet. 5. Face Coverings. Everyone at a job site must wear a face covering at all time, except children under the age of 2, people who are medically prevented from wearing a face covering, and for communication by or with people who are hearing impaired. 6. Sanitary Facilities. Ensure adequate handwashing and/or hand-sanitizing facilities are available at all times and encourage frequent handwashing and/or hand-sanitizing throughout the day as specified below. Portable sanitary facilities must be serviced and cleaned on a daily basis. Provide hand sanitizer in or around all toilet facilities and common areas, including project trailers. a. Handwashing. Wash hands using soap and water for at least 20 seconds. b. Hand-sanitizer. Use a hand sanitizer that contains at least 60-95% alcohol when handwashing is not immediately available. c. Paper Products. Ensure that toilet paper, tissues, and paper towels are available as appropriate, with designated receptacles for disposal. 7. Distancing. Prohibit workers from being less than six feet apart, unless and only to the extent that would compromise worker safety or violate safety Laws for specific operations. Prohibit handshaking or any physical contact among workers, with the sole and limited exception of any physical contact required for worker safety or to comply with safety Laws. Avoid sharing tools to the extent possible. Require workers to provide their own transportation where possible and to avoid having more than two workers in a vehicle. 8. Groups/Meetings/Site Access. Avoid any group gatherings of 10 or more people. Use electronic alternatives to in person meetings, e.g., conference calls, video-conferencing, etc., to the greatest extent possible. Limit access to the project site or any work area to workers who are necessary to perform the work at that time. Allow non-essential Revised: July 13, 2020 – Public Works Contracts 3 personnel to work from home to the extent possible. Avoid all non-essential travel. Do not stack trades if possible. 9. Frequent Cleaning. Provide for regular and appropriate cleaning of all high touch surfaces at a project site or work area, including, but not limited to, shared tools or equipment, doorknobs and handles, toolboxes, sanitary facilities, common break areas, keypads, touch screens, project trailer surfaces and equipment, light or power switches, workstations, countertops, break areas, and the like. Clean and/or disinfect any reusable items or equipment. Clean surfaces of shared vehicles, including steering wheels, gear shifts, handles, instrument panels, etc. Ensure that cleaning products are used correctly and safely, and avoid cleaning techniques, such as use of pressurized air or water sprays, that may generate bioaerosols. 10. Personal Protective Equipment. When workers cannot avoid close proximity or physical contact, e.g., based on applicable safety laws, or are otherwise at risk for exposure to COVID-19, ensure that the affected workers are provided with appropriate personal protective equipment ("PPE"), which may include disposable gloves and/or other PPE. Instruct workers to wash or sanitize hands after removing gloves or other PPE. Ensure that all personal protective equipment is disposed of properly. 11. Water and Food. Prohibit shared or communal food or common water coolers. Provide individual water bottles for workers or instruct workers to bring their own. 12. Enforcement. Immediately eject any worker who fails or refuses to comply with the Health Laws, Social Distancing Requirements, or these best practices from the project site until or unless the Project Manager issues a written authorization for the worker to return, subject to full compliance. F. Proof of Compliance. If Contractor is subject to the Mandatory Directive for Construction Projects, Contractor must provide to the City the name and contact information for its designated site-specific COVID-19 supervisor(s). E. Oversight. In other to ensure that all workers comply with the Social Distancing Requirements to the extent possible, Contractor shall designate a named individual to have primary responsibility for implementation and enforcement of the Social Distancing Requirements and these best practices, and to serve as the primary point of contact with the City in this regard. Contractor shall promptly inform the City of the name of this individual. F. Changed Requirements. It is understood and acknowledged that circumstances pertaining to the COVID-19 pandemic are evolving rapidly and that new local, state, or federal requirements may modify the requirements under this Exhibit. Contractor agrees to work cooperatively with the City to implement new or changed requirements as quickly as possible. Revised: July 13, 2020 – Public Works Contracts 4 G. Subcontracts. Contractor shall include the terms of this Exhibit in all subcontracts and require any agents, subcontractors, or subconsultants to comply with its provisions. Attachments to Exhibit A-A Santa Clara County Mandatory Directive for Construction Projects 1228578.5 County of Santa Clara Public Health Department Health Officer 976 Lenzen Avenue, 2nd Floor San José, CA 95126 408.792.5040 Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 1 of 12 Board of Supervisors: Mike Wasserman, Cindy Chavez, Dave Cortese, Susan Ellenberg, S. Joseph Simitian County Executive: Jeffrey V. Smith MANDATORY DIRECTIVE FOR CONSTRUCTION PROJECTS *Please confirm that your facility and/or construction project jobsite may open under the State Order. Where there is a difference between the local County Order and the State Order, the more restrictive order must be followed. The State also has specific guidance for certain facilities that must be followed in addition to this mandatory directive.* Issued: July 7, 2020 Information on the State’s Order and State guidance is available at covid19.ca.gov. While the construction industry is critical to ensuring a safe and sufficient supply of residential and commercial space, construction work can also pose significant risks to public health due to the COVID-19 pandemic. Because construction projects typically involve many workers actively working on a jobsite at the same time, often in close proximity to one another or sharing equipment, businesses and individuals performing and overseeing construction projects must take extra precautions to reduce the risk of COVID-19 transmission for workers, visitors, and others. This Directive applies to all construction projects, but the restrictions vary by the size of the project, as specified below. “Construction project” means any work (including a public works project) carried out in connection with the construction, alteration, conversion, fitting-out, remodel, renovation, refurbishment, demolition, decommissioning, or dismantling of a building or other structure; the preparation of a physical site for any such activity; and education or training at which any such activity is taught through onsite practice or experience. “Construction project” does not include architectural, design, financial, or administrative work related to a construction project, unless that work occurs at the construction jobsite. “Construction project” also does not include basic repair or maintenance work, which means a repair or maintenance job that requires no more than 2 workers and no more than 2 days and that is not architecturally, financially, or administratively associated with an active construction project. This Directive explains how construction projects may operate. This Directive is mandatory, and failure to follow it is a violation of the Health Officer’s Order issued on July 2, 2020 (“Order”). Construction projects must comply with the Order and all requirements of this Directive. Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 2 of 12 The Order Issued July 2 The Order imposes several restrictions on all businesses and activities to ensure that the County stays as safe as possible, including but not limited to the following: The Social Distancing Protocol: All businesses must fill out and submit the newest version of the Social Distancing Protocol to the County using the online form, available here. The Protocol is submitted under penalty of perjury, meaning that everything written on the form must be truthful and accurate to the best of the signer’s knowledge, and submitting false information is a crime. The Protocol must be distributed to all workers, and it must be accessible to all officials who are enforcing the Order. Businesses are responsible for ensuring that workers understand and are trained on Protocol requirements in a language that they understand. For any business that only performs services for dispersed facilities or worksites that the business does not own or operate, the business must complete a Social Distancing Protocol for its operation as a whole. For any business that has a facility, but also provides services at dispersed facilities or worksites that the business does not own or operate, the business must complete a Social Distancing Protocol for its own facility and provide that Protocol to the owners or operators of any facility where it operates.  Example: A construction company serves as a subcontractor on various jobsites throughout the County and also operates a base facility within the County, where it maintains its vehicles and equipment. The subcontractor must complete a Social Distancing Protocol for its base facility. It must also distribute the Protocol to the owners or operators of the jobsites to which it sends its workers. The subcontractor’s workers must be given a copy of, be trained on, and comply with the measures in both the subcontractor’s Social Distancing Protocol and the Social Distancing Protocol for any jobsite at which they are performing work. • Signage: All businesses must print (1) an updated COVID-19 PREPARED Sign and (2) a Social Distancing Protocol Visitor Information Sheet, and both must be posted prominently at all facility entrances. These are available for printing after submission of the Social Distancing Protocol online.  Businesses do not need to post these documents if they do not have their own facility or worksite and only perform services for dispersed facilities or worksites that the business does not own or operate. • Face Coverings: Everyone at a business facility or worksite must wear a face covering at all times (except very young children, people for whom face coverings are medically inadvisable, or for communication by or with people who are hearing impaired). Face coverings must be worn even while working at a construction project. Workers do not need to wear face covering if it would create a risk to the person related to their work, in accordance with local, state, or federal workplace safety guidelines. Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 3 of 12 • Density Limitation: All businesses must limit the number of people who may be inside the facility at the same time. For staff members, the limit is 1 person per 250 gross square feet of indoor facility space (this means total space, including areas open only to staff like storage rooms). For members of the public, the limit is 1 person per 150 square feet of space open to the public. The density requirements tell businesses how many people (staff or clients) they can let inside the facility before another person leaves. Children under 12 who are accompanying a parent or guardian do not count against the limit, but everyone age 12 and over does. This Directive describes a limited exception to the density limitation applicable only to construction project jobsites. See the Order and the FAQ page for more details. In addition to these general requirements applicable to all businesses under the Order, construction projects must comply with the following directives. Construction Projects on Own Residence Exempted This Directive does not apply to construction projects where a person is performing construction on their current residence alone or solely with members of their own household. Rules for Single-Worker Construction Projects This section lists the requirements for construction projects performed by only 1 worker, such as someone who is working alone on a kitchen remodel project. This section for single-worker projects does not apply to construction projects that involve multiple workers, even if only 1 worker is at the jobsite at any time; those projects must follow the Rules For All Construction Projects, which are listed in the next section. a. If the worker is working for a business, the worker must comply with the Social Distancing Protocol of that business. b. The worker must maintain 6 feet of social distance from all other people at all times, including when entering and leaving the work area or building. c. The worker must use and properly wear face coverings. In addition, the worker must wear other personal protective equipment (PPE) appropriate for use in construction, including gloves, goggles, and/or face shields. d. To the extent possible, the worker must seal off the work area so that there is a barrier between the worker and any other people in the building. For example, a worker performing construction in the hallway of a residence must install a barrier (such as plastic sheeting) between the area where the worker is working and the rest of the hallway. Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 4 of 12 e. The worker must frequently wash hands with soap and water for at least 20 seconds or use hand sanitizer with at least 60% alcohol. f. The worker must not work or come to the jobsite if the worker has a fever, cough, or any other COVID-19 symptoms. g. The worker must maintain records of the dates and times the worker was at the jobsite and must make those records immediately available upon request to any County official. h. If the worker tests positive for COVID-19, the worker must notify the County Public Health Department within 4 hours of learning of the positive result by following the instructions at www.sccsafeworkplace.org. Rules for All Construction Projects (Except Single-Worker Construction Projects) This section lists requirements for all construction projects (other than single-worker construction projects). *Note: Large Construction Projects must also follow additional requirements, which are described beginning on page 9.* 1. Responsibilities of the General Contractor and Subcontractors a. The business with the responsibility to oversee a construction project, described in this Directive as the “General Contractor,” must complete and submit a Social Distancing Protocol specific to the construction project jobsite. (The General Contractor may also need to submit social distancing protocols for its base facility or for other jobsites subject to this Directive.) b. The General Contractor is responsible for ensuring that all work and operations at the construction jobsite is performed in compliance with the Order, this Directive, and the jobsite-specific Social Distancing Protocol. c. The General Contractor must train its workers to comply with the Order, this Directive, and the jobsite-specific Social Distancing Protocol. d. Subcontractors do not need to submit their own jobsite-specific Social Distancing Protocols for the same site, but the General Contractor must not allow any subcontractor onto the jobsite unless that subcontractor has given the General Contractor a signed certification that: i. the subcontractor has reviewed the Order and this Directive and will comply with them; Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 5 of 12 ii. the subcontractor has reviewed the General Contractor’s jobsite-specific Social Distancing Protocol and trained its workers on that Protocol; and iii. the subcontractor has completed and submitted its own Social Distancing Protocol covering its operations, and has provided a copy of that Protocol to the General Contractor. 2. General Contractors and Subcontractors Must Report COVID-19 Positive Cases a. Whenever the General Contractor learns that a person who has tested positive for COVID-19 was at the jobsite within 48 hours of the date they were tested or within 48 hours of becoming symptomatic, the General Contractor must immediately implement the jobsite-specific Social Distancing Protocol’s procedures for when a person tests positive for COVID-19. All positive cases must be reported by following the instructions at www.sccsafeworkplace.org. b. All subcontractors must immediately (within 1 hour, regardless of the time of day) alert the General Contractor as soon as they learn that an employee has tested positive who is currently at the jobsite, or who was at the jobsite within 48 hours of the date they were tested or within 48 hours of becoming symptomatic. This reporting requirement is in addition to the subcontractor’s own reporting requirements under the Order and the procedures in the subcontractor’s Social Distancing Protocol. 3. Cleaning After Positive Case Identified Upon learning of a confirmed positive case at the jobsite within the last 48 hours, any location where the infected worker was known to have been present must be immediately closed and sanitized. Work in these locations must cease until sanitization is complete. 4. General Contractor is Responsible for Ensuring the Jobsite is Operated Safely Following All Legal Requirements a. The General Contractor must ensure that everyone at the jobsite—including its own workers, the subcontractors’ workers, and visitors—complies with the Order, this Directive, the jobsite-specific Social Distancing Protocol, and any other laws and regulations that apply to the work (for example, OSHA and Cal-OSHA requirements). If there is a conflict in what different laws require, the strictest standard applies. b. The General Contractor’s responsibility for ensuring jobsite compliance under this paragraph 4 does not, however, relieve any subcontractors of their own responsibilities under the Order, their Social Distancing Protocol, this Directive, and all other applicable laws and regulations. Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 6 of 12 c. Any worker, or any subcontractor, may file a complaint that the General Contractor has not complied with the Order, this Directive, or the jobsite-specific Social Distancing Protocol, or that the General Contractor has failed to require others to comply. Complaints may be filed through the County Office of Labor Standards Enforcement Advice Line (866-870-7725) or website (www.sccfairworkplace.org). 5. Designated COVID-19 Supervisor(s) a. The General Contractor must designate a site-specific COVID-19 Supervisor or Supervisors to enforce the jobsite-specific Social Distancing Protocol and this Directive. The designated COVID-19 Supervisor(s) must be present at the jobsite at all times during construction activities. The COVID-19 Supervisor may be an on-site worker who is designated to serve in this role. The General Contractor must prominently post a sign at all entrances to the jobsite clearly identifying the COVID-19 Supervisor(s) by name and providing their phone number and email address. b. The designated COVID-19 Supervisor(s) must review this Directive and the jobsite-specific Social Distancing Protocol with all workers and other persons at the jobsite. The General Contractor is responsible for making sure this occurs. c. The COVID-19 Supervisor must monitor and ensure implementation at the jobsite of all requirements in this Directive, the jobsite-specific Social Distancing Protocol, and the Order. 6. Seal Off Area of Construction Project from Other Parts of Occupied Sites Where construction work occurs within an occupied residential or commercial building, all of the following rules apply: a. Work areas must, to the extent feasible, be sealed off from the remainder of the building (and from the remainder of the unit, if work is performed within a residential unit) with physical barriers such as plastic sheeting or closed doors sealed with tape. b. If possible, workers must access the work area from entry/exit door(s) different from the entry/exit door(s) used by residents or occupants accessing the remainder of the building that is not under construction. c. Available windows and/or doors must be used to ventilate the work area during the workday and any other times work is performed. d. If residents or occupants have access to the work area between workdays, the Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 7 of 12 work area must be cleaned and sanitized at the beginning and at the end of workdays. e. Every effort must be taken to minimize contact between workers and residents or occupants, including maintaining a minimum of at least 6 feet of social distancing at all times. 7. Personal Protective Equipment (PPE) The General Contractor must obtain, provide at no cost to workers, and require that all workers use personal protective equipment (PPE) appropriate for use in construction, including gloves, goggles, face shields, and face coverings as appropriate for the activity being performed. Face coverings must be worn in compliance with the State’s mandatory Guidance for the Use of Face Coverings and any additional directives issued by the County Health Officer. At no time may medical-grade PPE be used at a construction site unless it is required due to the medical nature of the jobsite or local, state, or federal workplace safety requirements. 8. Social Distancing, Sanitizing, and other Measures a. The General Contractor must: i. Ensure compliance at the jobsite with the Order’s density limitations except to the extremely limited extent a higher density is temporarily necessary to safely carry out a specific job function. 1. The density limitations apply to all indoor areas where construction work is actively being performed. Density limitations do not apply to staging areas or lay-down areas that are separate from the area where construction work is actively being performed. ii. Stagger shifts, breaks, and trade-specific work as necessary to reduce density and allow for easy maintenance of minimum 6-foot distancing. Staggered shifts and breaks must comply with applicable wage and hour laws. 1. All persons must maintain minimum 6-foot distancing except to the extremely limited extent shorter distances are temporarily necessary to safely carry out a specific job function. iii. Eliminate or resolve “choke points” and “high-risk areas” where workers are unable to maintain 6-foot social distancing. The General Contractor must prohibit or limit use of these areas to ensure that 6-foot distance can easily be maintained between individuals. Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 8 of 12 iv. If possible, ensure workers eat their meals and take their breaks outdoors, and maintain social distancing during meals and breaks. v. Prohibit gatherings of any size on the jobsite (except for meetings required by this Directive), including gatherings for breaks or eating. Sharing of any food or beverage is strictly prohibited. vi. Cal-OSHA requires employers to provide water. Water must be provided in single-serve containers. vii. Prohibit use of microwaves, water coolers, and other similar shared equipment. b. Workers must: i. Unless strictly necessary to carry out a job function, maintain at all times at least 6-foot social distancing from fellow workers and all site visitors, including delivery workers, design professionals and other project consultants, government agency representatives (including building and fire inspectors), and residents at residential construction sites. ii. Not carpool to and from the jobsite except with others living within the same household unit, or if necessary because they have no alternative means of transportation. If workers from different households must carpool, they must wear face coverings while riding together in the same vehicle, sit at the greatest distance possible, and maintain ventilation by keeping windows open as feasible. 9. Notice for Workers and Visitors of Required Practices The General Contractor must prominently post a notice at all entrances to the jobsite visible to all workers and visitors instructing workers and visitors to do the following: a. Do not touch your face with unwashed hands or with gloves. b. If equipment is shared, it must be fully sanitized before and after each use. c. Wash your hands often with soap and water for at least 20 seconds each time, or use hand sanitizer with at least 60% alcohol. d. Clean and disinfect objects and surfaces you touch often, such as work stations, keyboards, telephones, handrails, machines, shared tools, elevator control buttons, and doorknobs. e. Cover your mouth and nose with a tissue or cloth when you cough or sneeze, or Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 9 of 12 cough or sneeze into your elbow/sleeve – never into your hands. f. Do not enter the jobsite if you have a fever, cough, or other COVID-19 symptoms. If you feel sick, or have been exposed to anyone who is sick, stay at home. g. Constantly make sure you are staying at least 6 feet away from co-workers at all times, unless it is absolutely necessary to get closer to complete a task for the construction project. h. Do not carpool to and from the jobsite with anyone except members of your own household, or if necessary because you have no alternative means of transportation. If you carpool with people from another household, you must wear a face covering while riding together in the same vehicle. i. Do not share phones or PPE. Posters conforming to this requirement are available for download at https://www.sccgov.org/sites/covid19/Pages/learn-what-to-do-flyers.aspx. 10. Cooperate with County’s Case Investigation and Contact Tracing Efforts The General Contractor must maintain a daily attendance log of all workers and visitors at the jobsite that includes contact information (including name, phone number, address, and email) and the date, time, and duration of each person’s presence at the jobsite. If someone on the jobsite tests positive for COVID-19, the General Contractor is legally required to assist the County Public Health Department in any case investigation and contact tracing efforts. 11. Monitor and Inform Supervisors and Subcontractors of Revised Requirements The General Contractor must regularly check for revisions to the Order, this Directive, relevant industry-specific guidance published by the California Department of Public Health, and other relevant rules or guidance. The General Contractor must inform all jobsite supervisors (including the designated COVID-19 Supervisor(s), all field supervisors, foremen, and safety directors) and all subcontractors of any revisions or additions to the requirements for construction projects. Additional Rules for Large Construction Projects This section describes additional requirements that apply only to Large Construction Projects. 12. What is a Large Construction Project? A “Large Construction Project” is a construction project that meets any of the following Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 10 of 12 specifications: a. For residential projects, any single-family, multi-family, senior, student, or other residential construction project consisting of 10 or more units; or b. For commercial projects, any construction project consisting of 20,000 or more square feet of floor area; or c. For mixed-use construction projects, any construction project that meets either of the specifications above in Subparagraphs (a) and (b); or d. Any infrastructure project that requires 20 or more workers at the jobsite at any one time. 13. COVID-19 Supervisor’s Additional Compliance, Monitoring, and Remediation Responsibilities a. The designated COVID-19 Supervisor must: i. Conduct daily briefings in person (with proper social distancing) or by teleconference that must cover the following topics: 1. New jobsite rules and pre-jobsite travel restrictions for the prevention of COVID-19 community spread. 2. Review of sanitizing and hygiene procedures. 3. Worker feedback on improving safety and sanitizing. 4. Coordination of construction site daily cleaning/sanitization requirements. 5. Any newly available information regarding COVID-19. 6. Emergency protocols in the event of an exposure or suspected exposure to COVID-19. ii. Each day, verify and record verification that each jobsite is compliant with this Directive. The General Contractor must collect each written verification, store them for at least 1 year, and make them immediately available upon request to any County official. iii. Conduct the following activities to make sure that the jobsite is ready to fix any violations of this Directive: Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 11 of 12 1. Develop a remediation plan; 2. If any non-compliance is identified, ensure that the remediation plan is implemented, and post the remediation plan at all entrances to the jobsite during the remediation period; 3. Stop any construction activity until the jobsite is back in compliance; and 4. Report repeated non-compliance with this Directive to the appropriate jobsite supervisors and the permitting agency for the local government where the project is located. b. The General Contractor is responsible for making sure the designated COVID-19 Supervisor takes all of these steps. 14. Jobsite Safety Accountability Supervisor (JSAS) The General Contractor must assign a COVID-19 Third-Party Jobsite Safety Accountability Supervisor (JSAS) for the jobsite. The JSAS may not be an employee of the General Contractor. The JSAS must at a minimum hold an OSHA-30 certificate and first-aid training, or equivalent credentials, from within the past 2 years. The JSAS must be trained in the requirements in this Directive and the jobsite-specific Social Distancing Protocol and must verify compliance with those requirements, including by visual inspection and random interviews with workers. The JSAS must inspect the jobsite as often as needed to ensure consistent compliance, but not less than once per week. The JSAS must inspect the jobsite during normal construction hours. a. The General Contractor must prominently post a sign at all entrances to the jobsite visible to all workers and visitors that clearly identifies the JSAS for the jobsite by name and providing their phone number and email address. b. Within 7 calendar days of each jobsite visit, the JSAS must complete a written assessment identifying any failure to comply with this Directive. The written assessment must be copied, stored, and, produced upon request to the County or local permitting agency. c. If the JSAS discovers that a jobsite is not in compliance with this Directive and the jobsite-specific Social Distancing Protocol, the JSAS must work with the designated COVID-19 Supervisor to develop and implement a remediation plan. d. The JSAS must coordinate with the designated COVID-19 Supervisor to prohibit continuation of any work activity not in compliance with this Directive or the jobsite-specific Social Distancing Protocol. The JSAS must make sure that the Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 12 of 12 work activity does not resume until the noncompliance is fixed and the continuing work is compliant with this Directive. e. The remediation plan must be sent to the local permitting agency and a designated County official within 5 calendar days of the JSAS’s discovery of the failure to comply. 15. Translation for Non-English-Speaking Workers The General Contractor must translate (and, where otherwise required, post) all of the following documents as necessary to ensure that all non-English-speaking workers are able to understand the documents: a. The Notice for Workers and Visitors of Required Practices described in Paragraph 9 (on page 8). b. The remediation plan described in Paragraph 13.a.iii.1 (on page 11). Stay Informed For answers to frequently asked questions about this industry and other topics, please see the FAQ page. Please note that this Directive may be updated. For up-to-date information on the Health Officer Order, visit the County Public Health Department’s website at www.sccgov.org/coronavirus. EX H I B I T B Sc h e d u l e o f P e r f o r m a n c e De s i g n P r o f e s s i o n a l s & C o n s u l t a n t C o n t r a c t s Ex h . B -Sc h e d u l e o f P e r f o r m a n c e f o r D e s i g n P r o f e s s i o n a l s & C o n s u l t a n t C o n t r a c t s - Re s i z e d 1 OCT NOV DEC JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC JAN FEB MAR CONSTRUCTION Pre-Construction Demolition Building Foundations Building Exterior Building MEP Interior Finishes Design Build Contract Completion Project Closeout and Turnover TOTALS Owner and CEO 8 8 8 8 8 8 8 8 8 8 8 8 8 8 8 8 8 8 144 Principal In Charge 12 12 12 12 12 12 12 12 12 12 12 12 12 12 12 12 12 12 216 Project Manager 45 45 45 20 20 20 20 20 20 20 20 20 20 20 20 20 20 20 435 Construction Manager 30 10 10 40 104 104 104 104 104 104 104 104 104 104 104 104 104 50 1492 Owner and CEO 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ 1,920$ NO CHARGE Principal In Charge 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ 2,520$ NO CHARGE Project Manager 8,325$ 8,325$ 8,325$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 3,700$ 80,475$ Construction Manager 5,250$ 1,750$ 1,750$ 7,000$ 18,200$ 18,200$ 18,200$ 18,200$ 18,200$ 18,200$ 18,200$ 18,200$ 18,200$ 18,200$ 18,200$ 18,200$ 18,200$ 8,750$ 261,100$ -$ -$ -$ -$ -$ -$ -$ -$ -$ -$ -$ -$ -$ -$ -$ -$ -$ -$ -$ 13,575$ 10,075$ 10,075$ 10,700$ 21,900$ 21,900$ 21,900$ 21,900$ 21,900$ 21,900$ 21,900$ 21,900$ 21,900$ 21,900$ 21,900$ 21,900$ 21,900$ 12,450$ 341,575$ MONTHLY STAFFING HOURS PROJECT PHASE 20212020 2022 EXHIBIT C Schedule of Compensation Design Professionals & Consultant Contracts Exh. C-Schedule of Compensation for Design Professionals & Consultant Contracts 1 GRIFFIN STRUCTURES FEE PROPOSAL LIBRARY EXPANSION PROJECT CITY OF CUPERTINO 10/06/2020 Griffin Structures’ Fee Proposal is based on all reasonable costs necessary to perform Project Management and Construction Management Services for the City of Cupertino’s Library Expansion Project. For these requisite services, Griffin Structures proposes the following Not to Exceed Fee: Project Management: $ 80,475 Construction Management: $ 261,100 Special Testing & Inspections: $ 60,000 Reimbursable Costs: $ 12,425 Base Contract Total $ 414,000 Contingency: $ 50,000 All proposed hourly rates are fully burdened and include overhead, profit, taxes, and benefits. The hours identified for each individual employee and task are estimates only and are not to be construed as not to exceed hours for any individual task, phase, or time-period. We reserve the right to reallocate hours between staff members and tasks to accomplish the overall objectives and requirements of the project. Services are based on the attached Fee Schedule, Resource Allocation Schedule, which provides detail on the allocation of hours. Any extension of the schedule or services may result in additional fee, in good faith negotiation with the City. APPROACH TO FEE AND PROJECT SCHEDULE This proposal assumes a project schedule as defined in the RFP and in consultation with the City: Pre-Construction Period: October 1, 2020 thru January 31, 2021 Construction Begins: February 2021 Construction Completion: December 2021 Project Closeout: January 2022 thru March 2022 EXHIBIT C Schedule of Compensation Design Professionals & Consultant Contracts Exh. C-Schedule of Compensation for Design Professionals & Consultant Contracts 2 To bring value to the City and to perform all tasks listed in the RFP, Griffin Structures proposes the following staffing allocation: Roger Torriero, as the CEO of Griffin Structures, will provide support and design build insight for the duration of this engagement and will dedicate a total of 144 hours of his time accordingly. To bring value to the City, Roger’s time is offered AT NO COST for a total VALUE ADDED of $34,560. Jon Hughes will service as Principal in Charge for the duration of the project and will provide direction and quality assurance to the project team for a total of 216 hours. To bring value to the City, Jon’s time is offered AT NO COST for a total VALUE ADDED of $45,360. Justin DiRico will serve as the Project Manager for the duration of the project and will provide as-needed leadership to the project team to deliver a successful project to the City. Specifically, Justin will bring extensive Design Build expertise to the team and ensure the Construction Manager and Design Build Entity (DBE) are functioning as a cohesive team to ensure successful delivery to the City. For this level of service this proposal allocates 435 hours of Justin’s time to the project. Hernan Munayco will serve as the Construction Manager for the duration of the project. In this role Hernan will serve as the direct interface between the DBE and the City to ensure the project is constructed consistent with the Bridging Documents and the construction activities do not interfere with Library operations. For this level of service, we have allocated roughly 3 days per week (104 hours per month) of Hernan’s time for a total allocation of 1492 hours. QUALIFICATIONS AND EXCLUSIONS 1.Hourly rates are valid through December 31, 2022 and will escalate by CPI annually thereafter. 2.Insurance costs are included as a reimbursable expense and will be billed monthly at the rate of $8 per $1,000. 3.On-site trailer rental, furniture, utilities, and sanitary facilities for our field staff are excluded. We assume that offices will be provided as part of the construction site trailer(s) being provided by the DBE. 4.Costs for all permits required for the project are excluded. It is assumed that the City will pay for all permitting fees, assessments, easements, school fees, and other agency or governmental fees or costs to support the design and construction the project. We have not included any permit related fees within our fee proposal. 5.Costs for surveying, construction staking, environmental and hazardous materials surveys, and all remediation costs are excluded. 6.Software licenses or user fees for specific project management software being required by either the City or their contractor(s) is excluded. It is assumed the DBE will provide the necessary EXHIBIT C Schedule of Compensation Design Professionals & Consultant Contracts Exh. C-Schedule of Compensation for Design Professionals & Consultant Contracts 3 electronic document management system and that the Project Manager and Construction Manager will have full access thereto. 7.Cost of bulk blueprinting for plans and specifications for use by the contractors and subcontractors is excluded. Funds included in reimbursable expenses are for Griffin printing costs alone. 8.Wage Compliance Program including Certified Payroll auditing, field interviews, or reporting is excluded. Based on State Law SB 854, it is assumed that the Dept. of Industrial Relations (DIR) will manage this effort at the State level. Griffin will enforce the Contractor registration requirements stipulated by the DIR. 9.Independent or third-party testing companies such as Roofing, Peer Reviews, or other specialized third-party oversight services other than those listed herein are excluded. 10.This proposal includes Special Inspection and Testing costs understood in coordination with the City to be reasonably sufficient for achieving occupancy. Nonetheless, inspections of this type are driven by Contractor means and methods and are therefore subject to Contractor efficiency or inefficiency. Any shortfall in Special Inspections and Testing will be negotiated in good faith with the City. 11.No FF&E or OS&E is included in this proposal 12.24-hour surveillance is excluded. 13.Construction Manager will review all RFI’s, Submittals, and Substitutions for completeness, approvals to be executed by the DBE Engineer of record. 14.This proposal does not include a formal independent Inspector of Record (IOR). All City Building Dept. Permit Inspections are assumed to be performed by the City Building Dept. EXHIBIT C Schedule of Compensation Design Professionals & Consultant Contracts Exh. C-Schedule of Compensation for Design Professionals & Consultant Contracts 4 EXHIBIT C Schedule of Compensation Design Professionals & Consultant Contracts Exh. C-Schedule of Compensation for Design Professionals & Consultant Contracts 5 EXHIBIT C Schedule of Compensation Design Professionals & Consultant Contracts Exh. C-Schedule of Compensation for Design Professionals & Consultant Contracts 6 Exh. D-Insurance Requirements for Design Professionals & Consultants Contracts 1 Form Updated Sept. 2019 Consultant shall procure prior to commencement of Services and maintain for the duration of the contract, at its own cost and expense, the following insurance policies and coverage with companies doing business in California and acceptable to City. INSURANCE POLICIES AND MINIMUMS REQUIRED 1. Commercial General Liability (CGL) for bodily injury, property damage, personal injury liability for premises operations, products and completed operations, contractual liability, and personal and advertising injury with limits no less than $2,000,000 per occurrence (ISO Form CG 00 01). If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO Form CG 25 03 or 25 04) or it shall be twice the required occurrence limit. a. It shall be a requirement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be made available to the Additional Insured and shall be (i) the minimum coverage/limits specified in this agreement; or (ii) the broader coverage and maximum limits of coverage of any insurance policy, whichever is greater. b. Additional Insured coverage under Consultant's policy shall be "primary and non-contributory," will not seek contribution from City’s insurance/self-insurance, and shall be at least as broad as ISO Form CG 20 01 (04/13). c. The limits of insurance required may be satisfied by a combination of primary and umbrella or excess insurance, provided each policy complies with the requirements set forth in this Contract. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary basis for the benefit of City before the City’s own insurance or self- insurance shall be called upon to protect City as a named insured. 2. Automobile Liability: ISO CA 00 01 covering any auto (including owned, hired, and non-owned autos) with limits no less than $1,000,000 per accident for bodily injury and property damage. 3. Workers’ Compensation: As required by the State of California, with Statutory Limits and Employer’s Liability Insurance of no less than $1,000,000 per occurrence for bodily injury or disease.  Not required. Consultant has provided written verification of no employees. 4. Professional Liability for professional acts, errors and omissions, as appropriate to Consultant’s profession, with limits no less than $2,000,000 per occurrence or $2,000,000 aggregate. If written on a claims made form: a. The Retroactive Date must be shown and must be before the Effective Date of the Contract. b. Insurance must be maintained for at least five (5) years after completion of the Services. c. If coverage is canceled or non-renewed, and not replaced with another claims-made policy form with a Retroactive Date prior to the Contract Effective Date, the Consultant must purchase “extended reporting” coverage for a minimum of five (5) years after completion of the Services. OTHER INSURANCE PROVISIONS The aforementioned insurance shall be endorsed and have all the following conditions and provisions: EXHIBIT D Insurance Requirements Design Professionals & Consultants Contracts Exh. D-Insurance Requirements for Design Professionals & Consultants Contracts 2 Form Updated Sept. 2019 Additional Insured Status The City of Cupertino, its City Council, officers, officials, employees, agents, servants and volunteers (“Additional Insureds”) are to be covered as additional insureds on Consultant’s CGL and automobile liability policies. General Liability coverage can be provided in the form of an endorsement to Consultant’s insurance (at least as broad as ISO Form CG 20 10 (11/ 85) or both CG 20 10 and CG 20 37 forms, if later editions are used). Primary Coverage Coverage afforded to City/Additional Insureds shall be primary insurance. Any insurance or self-insurance maintained by City, its officers, officials, employees, or volunteers shall be excess of Consultant’s insurance and shall not contribute to it. Notice of Cancellation Each insurance policy shall state that coverage shall not be canceled or allowed to expire, except with written notice to City 30 days in advance or 10 days in advance if due to non-payment of premiums. Waiver of Subrogation Consultant waives any right to subrogation against City/Additional Insureds for recovery of damages to the extent said losses are covered by the insurance policies required herein. Specifically, the Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of City for all work performed by Consultant, its employees, agents and subconsultants. This provision applies regardless of whether or not the City has received a waiver of subrogation endorsement from the insurer. Deductibles and Self-Insured Retentions Any deductible or self-insured retention must be declared to and approved by the City. At City’s option, either: the insurer must reduce or eliminate the deductible or self-insured retentions as respects the City/Additional Insureds; or Consultant must show proof of ability to pay losses and costs related investigations, claim administration and defense expenses. The policy shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the insured or the City. Acceptability of Insurers Insurers must be licensed to do business in California with an A.M. Best Rating of A-VII, or better. Verification of Coverage Consultant must furnish acceptable insurance certificates and mandatory endorsements (or copies of the policies effecting the coverage required by this Contract), and a copy of the Declarations and Endorsement Page of the CGL policy listing all policy endorsements prior to commencement of the Contract. City retains the right to demand verification of compliance at any time during the Contract term. Subconsultants Consultant shall require and verify that all subconsultants maintain insurance that meet the requirements of this Contract, including naming the City as an additional insured on subconsultant’s insurance policies. Higher Insurance Limits If Consultant maintains broader coverage and/or higher limits than the minimums shown above, City shall be entitled to coverage for the higher insurance limits maintained by Consultant. Adequacy of Coverage City reserves the right to modify these insurance requirements/coverage based on the nature of the risk, prior experience, insurer or other special circumstances, with not less than ninety (90) days prior written notice. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY 10/6/2020 Dealey,Renton &Associates License #0020739 600 Anton Boulevard,Suite 100 Costa Mesa CA 92626 714-427-6810 714-427-6818 certificates@dealeyrenton.com Great American Insurance Company of NY GRIFFSTRU Great American Assurance Company 26344GriffinStructuresInc 2 Technology Dr.,Ste.150 Irvine CA 92618 Oak River Insurance Company 34630 Lexington Insurance Company 19437 United Financial Casualty Company 1742612703 B X 1,000,000 X 50,000 X Contractual Excluded X BFPD,XCU 1,000,000 2,000,000 X GLP2969834 12/31/2019 12/31/2020 2,000,000 E 1,000,000 X X X 064097132 12/31/2019 12/31/2020 A X X 4,000,000EXC296983512/31/2019 12/31/2020 4,000,000 C XGRWC91314612/31/2019 12/31/2020 1,000,000 1,000,000 1,000,000 D Professional Liability Claims Made 028174885 12/31/2019 12/31/2020 per claim annl aggr. $2,000,000 $4,000,000 $25,000 Deductible Umbrella policy is a follow-form to underlying General Liability/Auto Liability/Employers Liability. Re:All Operations as pertains to named insured. The City of Cupertino,its City Council,officers,officials,employees,agents,servants and volunteers are Additional Insured as respects to General Liability as required per written contract or agreement.Insurance coverage includes waiver of subrogation per the attached. 30 Days Notice of Cancellation The City of Cupertino 10300 Torre Ave Cupertino CA 95014 Copyright, ISO Properties, Inc.,2004 CG 20 33 (Ed. 07/04) XS CG 20 33 (Ed. 07 04) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONT RACTORS - AUTOMATIC STATUS WHEN REQUIRED IN CONSTRUCTION AGREEMENT WITH YOU This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART A. SECTION II - WHO IS AN INSURED is amended to include as an Additional Insured any person or organization for whom you are performing operations when you and such person or organization have agreed in writing in a contract or agreement that such person or organization be added as an Additional In- sured on your policy. Such person or or- ganization is an Additional Insured only with respect to liability for "bodily injury," "prop- erty damage" or "personal and advertising in- jury" caused, in whole or in part, by: 1.your acts or omissions; or 2.the acts or omissions of those acting on your behalf; in the performance of your ongoing oper- ations for the Additional Insured. A person's or organization's status as an Ad- ditional Insured under this endorsement ends when your operations for that Additional In- sured are completed. B.With respect to the insurance afforded to these Additional Insureds, the f ollowing addi- tional exclusions apply: This insurance does not apply to: 1."Bodily injury," "property damage" or "per- sonal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural,engineering or surveying services, including: a.the preparing,approving, or failing to prepare or approve, maps, shop drawings,opinions, reports, surveys, field orders, change orders or draw- ings and specifications; or b.supervisory, inspection, architectural or engineering activities. 2."Bodily injury," or "property damage" oc- curring after: a.all work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the Additional Insured(s) at the location of the covered operations has been completed; or b.that portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than an- other contractor or subcontractor en- gaged in performing operations for a principal as a part of the same project. Great American Assurance Company1PMJDZ GLP2969834 GAC 3649CG (Ed. 11/06) XS GAC 3649CG (Ed. 11 06) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARY NON-CONTRIBUTORY INSURANCE ENDORSEMENT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM OWNERS AND CONTRACTORS PROTECTIVE LIABILITY COVERAGE FORM This insurance is primary to any other insurance held by third parties with respect to work performed by you under written contractual agreements with such third parties and any other insurance which may be available to such third parties shall be non-contributory. Great American Assurance Company 1PMJDZ GLP2969834 Great American Assurance Company THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART Schedule © Insurance Services Office, Inc., 2008 CG 24 04 (Ed. 05/09) (Page 1 of 1) Name of Person or Organization: Any person or organization for whom or on whose behalf "you" are performing operations when "you" and such person or organization have agreed in writing in a contract or agreement to waive any right of recovery "we" may have against such person or organization. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to paragraph 8. Transfer of Rights of Recovery Against Others to Us of SECTION IV - CONDITIONS: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products-completed operations hazard." This waiver applies only to the person or organization shown in the Schedule above. CG2404(Ed.05/09) 3ROLF\ GLP2969834 GRWC913146 Griffin Structures Amendment #1 for Project Management & Construction Management for the Library Expansion Project Final Audit Report 2022-02-09 Created:2022-02-04 By:City of Cupertino (webmaster@cupertino.org) Status:Signed Transaction ID:CBJCHBCAABAAqL7WBTa2HaK6tg3y4bwjB50Z8W9JKRYs "Griffin Structures Amendment #1 for Project Management & Co nstruction Management for the Library Expansion Project" Histor y Document created by City of Cupertino (webmaster@cupertino.org) 2022-02-04 - 1:20:59 AM GMT- IP address: 35.229.54.2 Document emailed to Julia Kinst (juliak@cupertino.org) for approval 2022-02-04 - 1:23:44 AM GMT Document approved by Julia Kinst (juliak@cupertino.org) Approval Date: 2022-02-04 - 1:24:13 AM GMT - Time Source: server- IP address: 216.198.111.214 Document emailed to Araceli Alejandre (aracelia@cupertino.org) for approval 2022-02-04 - 1:24:16 AM GMT Document approved by Araceli Alejandre (aracelia@cupertino.org) Approval Date: 2022-02-04 - 2:05:30 AM GMT - Time Source: server- IP address: 73.170.27.253 Document emailed to Jon Hughes (jhughes@griffinstructures.com) for signature 2022-02-04 - 2:05:32 AM GMT Email viewed by Jon Hughes (jhughes@griffinstructures.com) 2022-02-04 - 7:07:41 AM GMT- IP address: 13.57.238.31 Document shared with susanm@cupertino.org 2022-02-08 - 6:23:12 PM GMT- IP address: 216.198.111.214 Email viewed by Jon Hughes (jhughes@griffinstructures.com) 2022-02-09 - 1:18:53 AM GMT- IP address: 54.219.183.184 Document e-signed by Jon Hughes (jhughes@griffinstructures.com) Signature Date: 2022-02-09 - 1:19:29 AM GMT - Time Source: server- IP address: 64.147.1.217 Document emailed to Christopher D. Jensen (christopherj@cupertino.org) for signature 2022-02-09 - 1:19:33 AM GMT Email viewed by Christopher D. Jensen (christopherj@cupertino.org) 2022-02-09 - 1:48:31 AM GMT- IP address: 104.47.73.126 Document e-signed by Christopher D. Jensen (christopherj@cupertino.org) Signature Date: 2022-02-09 - 1:48:58 AM GMT - Time Source: server- IP address: 50.216.25.242 Document emailed to Jim Throop (jimt@cupertino.org) for signature 2022-02-09 - 1:49:01 AM GMT Email viewed by Jim Throop (jimt@cupertino.org) 2022-02-09 - 9:04:29 PM GMT- IP address: 104.47.74.126 Document e-signed by Jim Throop (jimt@cupertino.org) Signature Date: 2022-02-09 - 9:05:48 PM GMT - Time Source: server- IP address: 64.165.34.3 Document emailed to Kirsten Squarcia (kirstens@cupertino.org) for signature 2022-02-09 - 9:05:51 PM GMT Email viewed by Kirsten Squarcia (kirstens@cupertino.org) 2022-02-09 - 9:11:14 PM GMT- IP address: 104.47.73.126 Document e-signed by Kirsten Squarcia (kirstens@cupertino.org) Signature Date: 2022-02-09 - 9:11:23 PM GMT - Time Source: server- IP address: 69.110.137.176 Agreement completed. 2022-02-09 - 9:11:23 PM GMT