Loading...
21-032 Installation Agreement, 10583 Santa Lucia Rd APN 342-17-002RECORDING REQUESTED BY City of Cupertino WHEN RECORDED, MAIL TO: City Clerk's Office City of Cupertino 10300 Torre Avenue Cupertino, CA 95014-3255 NO FEE IN ACCORDANCE WITH GOV. CODE 27383 24895392 Regina Alcomendras Santa Clara County - Clerk -Recorder 03/29/2021 11:19 AM Titles: 1 Pages: 24 Fees: $0.00 Taxes: 0 Total: 1``0.00 {, ` IIj y �M1 ICI 1111 `i d ` ",IIfig I'41I'I�tiL}•��'�ti�� (SPACE ABOVE THIS LINE FOR RECORDER'S USE) INSTALLATION AGREEMENT 10583 Santa Lucia Road, Cupertino, CA 95014 APN 342-17-002 Original 0 Conformed Copy City of Cupertino INSTALLATION AGREEMENT (Cupertino Municipal Code Chapter 14.04) 10583 Santa Lucia Road, Cupertino, CA 95014 APN 342-17-002 This INSTALLATION AGREEMENT ("Agreement") for street improvements is made and entered into this j {&—day of )lee E-W hP. V'*� , 20�, by and between the CITY OF CUPERTINO, a municipal corporation of the State of California, ("CITY"), and 10583 Santa Lucia Investment LP ("DEVELOPER") for a single family development located at 10583 Santa Lucia Road, Cupertino, CA 95014 (APN 342-17-002). RECITALS 1. DEVELOPER has presented to the City an application for a development entitlement consisting of a single family development (the "Development Entitlement") located at 10583 Santa Lucia Road, Cupertino CA (the "Property"). 2. Chapter 14.04 of the Cupertino Municipal Code ("CIVIC") requires, as a condition precedent to the erection, construction, addition, alteration or repair of any building or structure in certain designated areas of the City with unimproved streets and for which a building permit is required by the City, installation of certain types of public improvements and/or dedication where deemed necessary by the City Engineer. 3. In consideration of City's approval of the Development Entitlement and pursuant to the requirements of CMC Chapter 14.04, Developer desires to enter into this Agreement promising to install and complete, at Developer's sole expense, all public improvement work required by the City for the proposed development. 4. Developer has prepared and City has approved plans and related specifications (the "Improvement Plans") for construction, installation and completion of improvements. The Improvement Plans titled New Residence, 10583 Santa Lucia Road, Cupertino, CA, prepared by WEC & Associates and dated August, 2020, are hereby incorporated into this Agreement by reference. NOW, THEREFORE, in consideration of the approval by City of the Development Entitlement, City and Developer agree as follows: 1. DEVELOPER'S OBLIGATION TO INSTALL IMPROVEMENTS a. Completion of Improvements. Developer, at its own expense, shall furnish, install, and construct all improvements required by the City Engineer pursuant to Chapter 14.04 of the Page 1 of 11 Cupertino Municipal Code, or as amended, in a good and workmanlike manner and as shown on the Improvement Plans as approved by the City Engineer of Cupertino and in accordance with existing ordinances and resolutions of the CITY and other applicable laws. The decision of the City Engineer shall be final as to whether any material or workmanship meets the plans, specifications, and standards as set forth. b. Compliance with applicable laws and rules. Developer shall complete the Work in accordance with the most current Standard Specifications of the Department of Public Works, California Department of Transportation, State of California, and in accordance with the specifications of the Cupertino Sanitary District where applicable. Wherever the words "State" or "California Division of Highways" are mentioned in the State Specifications, it shall be considered as referring to the City of Cupertino; also wherever the "Director" or "Director of Public Works" is mentioned, it shall be considered as referring to the City Engineer. In case of conflict between the State Specifications and the specifications of the CITY, and/or the Cupertino Sanitary District, the specifications of the CITY and/or the Cupertino Sanitary District shall take precedence over and be used in lieu of such conflicting portions. Developer shall acquire all necessary permits, including an encroachment permit from the City of Cupertino Public Works Department, prior to beginning work in the public right of way. c. Repair and replacement of damaged public facilities. Developer shall, at its own expense, repair or replace all public improvements, public utility facilities, surveying monuments and other public facilities that are destroyed or damaged as a result of any work under this agreement. Developer shall promptly notify the City Engineer of such damage and shall obtain the City Engineer's approval of all repair and replacement of damaged facilities. d. Developer's responsibility until City's acceptance. Until City accepts the Improvements, Developer shall be responsible for the care and maintenance of such improvements and shall bear all risks of loss or damage to the improvements. City shall not have any liability for any accident, loss or damage to the Improvements prior to their completion and acceptance by City. City's acceptance of the Improvements shall not constitute a waiver of any defects in the Improvements or Developer's obligation to repair such defects as provided in section 8 of this Agreement. 2. TIME FOR INSTALLATION OF IMPROVEMENTS a. Required time of completion. DEVELOPER shall install and complete the Improvements within one (1) year from the date of execution of this AGREEMENT, or such longer period as may be specifically authorized in writing by the City Engineer. In the event the DEVELOPER fails or refuses to complete the Work within the specified period of time, the CITY, at its sole option, shall be authorized to complete the Work in whatever manner the CITY shall decide. In the event the CITY completes the Work, the CITY may recover any and all costs incurred thereby from the DEVELOPER or the DEVELOPER'S surety or both. No final inspection shall be granted or street improvements shall not be accepted unless all the requirements for safety purposes are installed, such as sidewalks, handicap ramps, street lights, etc. Page 2 of 11 3. DEDICATION OF EASEMENTS OR RIGHTS OF WAY The DEVELOPER offers to dedicate to the City fee title to the real property shown on Exhibit "A" and "B", which is attached hereto and made a part hereof by reference (the "Dedicated Property"). Upon the condition precedent that the DEVELOPER shall perform each and every covenant and condition of this AGREEMENT, the CITY agrees to accept said real property offered for dedication. The Dedicated Property shall be free and clear of all liens or encumbrances except those which the CITY agrees to waive in writing. Developer agrees not to revoke this offer of dedication, and to keep said offer open until the CITY accepts offer. Upon execution of this Agreement, Developer agrees to deliver a properly executed grant deed to the CITY of the real property described in Exhibit "A" and "B", and such other executed conveyances, or instruments necessary to convey clear title as herein required. The DEVELOPER shall provide, at the DEVELOPER'S sole cost and expense, to the City at the time of acceptance of dedication and recordation of deed, (1) a preliminary title report issued by a title insurance company relating to the property offered for dedication, and (2) a standard policy of title insurance issued by a title insurance company and insuring the CITY, showing that the Dedicated Property is free and clear of all liens or encumbrances except any that the City expressly agreed to waive. 4. QUITCLAIM DEED DEVELOPER, when requested by the CITY, shall quitclaim all his/her rights and interests in, and shall grant to CITY authorization to extract water from the ;underground strata lying beneath said project. DEVELOPER agrees to execute a "Quitclaim Deed and Authorization" in favor of CITY, when presented to him/her for signature. 5. SECURITY a. Required Security. Prior to execution of this Agreement, Developer shall provide the following security to City in a form acceptable to the City: (1) Faithful performance. Security for faithful performance in the amount set forth Part A Exhibit C the SCHEDULE OF BONDS, FEES AND DEPOSITS, attached and incorporated by reference as Exhibit D. (2) Labor and Materials. Security for labor and materials in the amount set forth Part B of Exhibit C the SCHEDULE OF BONDS, FEES AND DEPOSITS, attached and incorporated by reference as Exhibit E. b. Form of Security. Developer shall provide as security, bonds executed by a surety company authorized to transact a surety business in the State of California and approved by the City as to sufficiency. In the event that the DEVELOPER shall fail to faithfully perform the covenants and conditions of this AGREEMENT, or to make any payment, or any dedication of land, or any improvements herein required, the CITY shall call on the surety to perform this AGREEMENT or otherwise indemnify the CITY for the DEVELOPER'S failure to do so. Page 3 of 11 In lieu of a surety bond, the DEVELOPER may elect to secure this AGREEMENT by depositing with the CITY (1) Cash; (2) A cashier's check, or a certified check payable to the order of the City of Cupertino; or (3) A certificate of deposit, or instrument of credit acceptable to the City and meeting the requirements of Government Code Section 66499 (b) or (c). The amount of said cash, checks, certificate of deposit, or instrument of credit shall be as designated by the City Engineer, and shall be the equivalent to that which would have been required had the DEVELOPER furnished the CITY with a faithful performance surety bond. In the event that the DEVELOPER shall fail to faithfully perform the covenants and conditions of this AGREEMENT, or to make any payment, or any dedication of land, or any improvements herein required, the CITY may apply the proceeds of said security thereto. c. Release of Security. No release of surety bond, cash deposit, check or certificate of deposit shall be made except upon approval of the Director of Public Works. Schedule for bond and insurance release for paper bonds are as follows: (1) Release of 90 percent of the faithful performance bond upon acceptance by the Director of Public Works. (2) Release of the remaining 10 percent of the performance bond at one year from acceptance after all deficiencies have been corrected and in the absence of any claim against such bond. (3) Release of the entire labor and material bond at six months from acceptance after all deficiencies have been corrected and in the absence of any claim against such bond. (4) Liability insurance, provided by the DEVELOPER to hold the CITY harmless in the event of liability arising from the project, to be retired at the end of one year if all deficiencies have been corrected and in the absence of any claim against such insurance. 6. PAYMENT OF REQUIRED FEES a. Permits and licenses. Developer shall, at its sole expense, obtain all necessary permits and licenses for the construction and installation of the Improvements, give all necessary notices, and pay all fees required by City ordinance, including but not limited to the fees described in this Agreement, and all taxes required by law. b. Fees. Developer shall pay fees in the amounts set forth in Exhibit C, including but not limited to the following, as required: (1) Inspection Fees. DEVELOPER shall pay any and all necessary direct expenses for inspection, checking, etc. incurred by CITY in connection with said Project, and that DEVELOPER shall have deposited with CITY all such amounts prior to execution of this AGREEMENT. Should construction cost vary materially from the estimate from which said sum is calculated, the City Engineer shall notify DEVELOPER of any additional sum due and owing as a result thereof. (2) Storm Drainage Fee. DEVELOPER shall deposit with the CITY, prior to execution of this AGREEMENT, a storm drainage charge in connection with the said Project in accordance with the requirements established in Resolution 4422, March 21, 1977. Page 4 of 11 (3) Map Checking Fee. DEVELOPER shall deposit with CITY, prior to execution of this AGREEMENT, for office checking of final map and field checking of street monuments, in compliance with Section 4:1 of Ordinance No. 47 (Revised 12/04/61) of CITY. (4) Park Fee. DEVELOPER shall pay such fees and/or dedicate such land to the CITY, prior to execution of this AGREEMENT, as is required within Section 18-1.602, Park Land Dedication, Cupertino Municipal Code. Park fees are calculated in accordance with action adopted by the City Council on March 19, 1991 and Chapter 14.05 or Section 18-1.602 of the Cupertino Municipal Code. 7. STREET TREE INSTALLATION DEVELOPER shall fund the City for purchase and planting of street trees as deemed appropriate by the City Engineer; or shall, at the discretion and at such time as deemed appropriate by the City Engineer, plant street trees in conformance with the standards of the City of Cupertino. The variety, number and location of trees are subject to City's prior approval. 8. MAINTENANCE AND WARRANTY a. Developer guarantees and warrants the Improvements and agrees to remedy any defects, damages, or imperfections in the Improvements arising from faulty or defective materials or construction of the Improvements for a period of one year after City's acceptance of the Improvements. b. If, within the warranty period, the Improvements or any part of the Improvements fail to fulfill any of the requirements of this Agreement or the Improvement plans and specifications, Developer shall repair, replace or reconstruct any defective or otherwise unsatisfactory parts of the Improvements without delay and at no cost to City. If (a) Developer fails to commence repairs within thirty (30) days of the date of mailed written notice from City, or (b) City determines that public safety requires repair before Developer can be notified, City may, at its sole option, perform the required repair itself. Developer agrees to pay the cost of any repairs City performs pursuant to this agreement and City may, at its option, recover that cost as a lien against Developer's property. 9. SANITARY DISTRICT DEVELOPER shall file with the CITY, upon execution of this AGREEMENT, a letter from the Cupertino Sanitary District stating that the DEVELOPER has submitted plans for review by the District and that sanitary sewers are available to serve all lots within said Project. 10. GOVERNMENT COSTS DEVELOPER shall file with the CITY, upon execution of this AGREEMENT, substantial evidence that all provisions of Section 66493, Article 8, Chapter 4 of the Government Code, pertaining to special assessments or bonds, have been complied with. Page 5 of 11 11. UTILITIES DEVELOPER shall pay to Pacific Gas and Electric Company, AT&T, and/or appropriate utility companies, any and all fees required for installation of overhead and/or underground wiring circuits to all electroliers within said property and any and all fees required for undergrounding as provided in Ordinance No. 331 of CITY when the DEVELOPER is notified by either the City Engineer, Pacific Gas and Electric Company, AT&T, or appropriate utility companies that said fees are due and payable. 12. EASEMENTS AND RIGHT-OF-WAY Developer shall acquire any easement and right-of-way necessary for completion of the Project at its own cost and expense. However, that in the event eminent domain proceedings are required, the CITY for the purpose of securing said easement and right-of-way, DEVELOPER shall deposit with CITY, a sum covering the reasonable market value of the land proposed to be taken and, to be included in said sum, shall be a reasonable allowance for severance damages, if any. It is further provided that in addition thereto, such sums as may be required for legal fees and costs, engineering, and other incidental costs in such reasonable amounts as the CITY may require, shall be deposited with the City of Cupertino. 13. HOLD HARMLESS AND INDEMNIFICATION To the fullest extent allowed by law, DEVELOPER shall indemnify and hold harmless CITY, its City Council, boards and commissions, officers, officials, agents, employees, servants, consultants and volunteers (hereinafter, "indemnitees") from and against any liability, loss, damage, expense, and cost (including reasonable legal fees and costs of litigation or arbitration), resulting from injury to or death of any person, damage to property, or liability for other claims, stop notices, demands, causes of actions and actions, arising out of or in any way related to Developer's performance or nonperformance of his/her duties under this Agreement, or from negligent acts or omissions or willful misconduct of Developer, its agents, employees, contractors, or subcontractors. Developer shall, at his/her own cost and expense, defend any and all claims, actions, suits or legal proceedings that may be brought against the City or any of the Indemnitees (with council acceptable to City) in connection with this Agreement or arising out of Developer's performance or nonperformance of his/her duties and obligations hereunder, except to the extent any of the foregoing is caused by the negligence or willful misconduct of the CITY or the CITY'S agents, employees and independent contractors. 14. INSURANCE Prior to commencing any of the Public Improvements or Work referenced in this Agreement, DEVELOPER shall procure and maintain for the duration of the contract, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by Developer, its contractor, agents, representatives, employees or subcontractors. Page 6 of 1 l Coverage shall be at least as broad as: 1. Commercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an "occurrence" basis, written on a comprehensive general liability form, and must include coverage for liability arising from Developer's Contractors acts or omissions, including Contractor's protected coverage, blanket contractual, products and completed operations, vehicle coverage and employer's non -ownership liability coverage, with limits of at least $2,000,000 per occurrence. The CGL policy must protect against any and all liability for personal injury, death, property damage or destruction, and personal and advertising injury. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit. a. Any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be made available to the Additional Insured and shall be (1) the minimum coverage/limits specified in this agreement; or (2) the broader coverage and maximum limits of coverage of any insurance policy, whichever is greater. b. Additional Insured coverage under Developer's policy shall be "primary and non- contributory" and shall be at least as broad as ISO CG 20 0104 13. c. The limits of insurance required may be satisfied by a combination of primary and umbrella or excess insurance, provided each policy complies with the requirements set forth in this Contract. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of City before the City's own insurance or self-insurance shall be called upon to protect City as a named insured. 2. Automobile Liability covering owned, hired, and non -owned autos, with limit no less than $1,000,000 per accident for bodily injury and property damage. 3. Workers' Compensation: As required by the State of California, with Statutory Limits, and Employer's Liability Insurance of no less than $1,000,000 per accident for bodily injury or disease. If Developer maintains broader coverage and/or higher insurance limits, City will be entitled to Developer's broader coverage and/or higher limits. The City of Cupertino, its City Council, officers, officials, employees, agents, servants and volunteers are to be covered as additional insureds on the CGL policy. Endorsement of CGL coverage shall be at least as broad as ISO Form CG 20 10 1185 or if not available, through the addition of both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 if a later edition is used. For any claims related to this Agreement or the Work, Developer's insurance shall be "primary and non-contributory" and at least as broad as ISO CG 20 0104 13 with respect to City, its officers, officials, employees and volunteers, and shall not seek contribution from City's insurance. If the limits of insurance are satisfied in part by Umbrella/Excess Insurance, the Umbrella/Excess Insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a "primary and non-contributory" basis for the benefit of City. Page 7 of 11 Each insurance policy must provide that coverage will not be canceled, except with 30 days' notice to City. Each certificate of insurance must state that the coverage afforded by the policy is in force and will not be reduced, cancelled or allowed to expire without at least 30 days advance written notice to City, unless due to non-payment of premiums, in which case ten days advance written notice must be provided to City. Such notice must be sent to City via certified mail and addressed to the attention of the City Manager. Each required policy must include an endorsement providing that the carrier agrees to waive any right of subrogation it may have against City. Further, Developer agrees to waive any rights of subrogation which any of Developer's insurers may acquire from Developer by virtue of payment of any loss. Developer agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation. The Workers' Compensation policy must be endorsed with a waiver of subrogation in favor of the City for all work performed by Developer or Developer's Contractor, its employees, agents and subcontractors. Insurance must be issued by insurers licensed in the State of California and with an A.M. Best's financial strength rating of "A VII" or better. 15. MAPS AND/OR IMPROVEMENT PLANS Developer shall provide CITY with the following maps and/or plans at the DEVELOPER'S expense: A. A mylar blackline of fully executed parcel map. B. A scan in raster format of all executed improvement plans and map. 16. SUCCESSORS AND ASSIGNS -COVENANT RUNNING WITH THE LAND This Agreement shall inure to the benefit of, and be binding upon the heirs, administrators, successors, assigns and transferees of the Parties, and shall be recorded in the Office of the County Recorder and constitute a covenant running with the land. Upon any sale or division of the Property, the terms, covenants, conditions and restrictions of this agreement shall apply to each parcel, and the owner or owners of each parcel shall succeed to the obligations imposed upon developer by this Agreement. 17. FAILURE TO PERFORM In the event developer fails to perform one or more of the covenants and conditions of this agreement, City at its option shall have recourse to the security given to guarantee the performance of such acts. City may, at its option, do or cause to be done, the acts required of Developer and shall have recourse against as much of the security is necessary to discharge Developer's responsibility. City shall also have recourse against developer for any and all amounts necessary to complete the obligations of developer in the event that the security is insufficient to Page 8 of 1 I pay such amounts. All administrative costs, including reasonable attorney's fees incurred by City in addition to the costs of the improvements shall be proper charges against the security and Developer. 18. NOTICES All notices, demands, requests or approvals to be given under this Agreement shall be given in writing and conclusively shall be deemed served when delivered personally or on the second business day after the deposit thereof in the United States Mail, postage prepaid, registered or certified, addressed as hereinafter provided. All notices, demands, requests, or approvals from Developer to City shall be addressed to City at: City of Cupertino 10300 Torre Ave. Cupertino CA 95014 Attention: Public Works Director All notices, demands, requests, or approvals from City to Developer shall be addressed to Developer at: 10583 Santa Lucia Investment LP 22330 Santa Paula Ave. Cupertino, CA 95014 Attention: Tracy Hsu 19. GOVERNING LAW AND ATTORNEY FEES This Agreement shall be interpreted under, and enforced by the laws of the State of California excepting any choice of law rules which may direct the application of laws of another jurisdiction. The Agreement and obligations of the parties are subject to all valid laws, orders, rules, and regulations of the authorities having jurisdiction over this Agreement (or the successors of those authorities.) Any suits brought pursuant to this Agreement shall be filed with the courts of the County of Santa Clara, State of California. If City sues to compel Developer's performance of this Agreement, or to recover damages or costs incurred in completing or maintaining the work on the Improvements, Developer agrees to pay all attorney's fees and other costs and expenses of litigating incurred by the City, even if Developer subsequently resumes and completes the work. 20. RELATIONSHIP OF PARTIES Neither Developer nor any of its contractors, employees or agents shall be deemed to be agents of the City in connection with the Performance of Developer's obligations under this agreement. 21. SEVERABILITY The provisions of this Agreement are severable. If any portion of this Agreement is held invalid by a court of competent jurisdiction, the remainder of the agreement shall remain in full force and effect. Page 9 of 11 22. INTEGRATED AGREEMENT This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions hereof. Any modification of this Agreement will be effective only by written execution signed by both City and Developer. All unchecked boxes do not apply to this Agreement. IN WITNESS WHEREOF, the Parties have caused this agreement to be executed by their respective, duly authorized officers on the date listed above. Approved as to form: Heather Minner City Attorney Attach Notary acknowledgement CITY OF CUPERTINO: Roger/C6e Director of Public Works DEVELOPER: 10583 Santa Lucia Investment LP T acy Hsu, a(nager Exhibits: Exhibits A & B- Dedicated Property Exhibit C - Schedule of Bonds, Fees and Deposits Exhibit D - Faithful Performance Bond Exhibit E - Labor and Materials Bond Page 10 of 11 EXHIBIT "A" LEGAL DESCRIPTIONS DEDICATION FOR STREET PURPOSE Being a portion of Lot 134 and 135, as shown upon that certain map entitled "Map of Inspiration Heights Monta Vista", which map was filed for record in the Office of the Recorder of the County of Santa Clara, State of California, on April 11, 1917 in Book "P" of Maps, at Page 13, more particularly described as follows: Beginning at the Southeasterly corner of Lot 134, in the center line of Santa Lucia Road; thence along the southerly line of Lot 134, North 89°56'30" West, 30.00 feet; thence parallel to the center line of Santa Lucia Road, North 0°03'30" East, 130.00 feet; thence parallel to the southerly line of Lot 134, South 89°56'30" East, 30.00 feet; thence along the center line of Santa Lucia Road, South 0°03'30" West, 130.00 feet to the POINT OF BEGINNING. Containing an area of 3,900.0 square feet, more or less. Said lands are shown on attached plat Exhibit B and made a part hereof. �1\ IN! 0 RA J 2 31 2f _ P L.8235 cS� of CAt�°' . I,30(ZO2.0 Date N APN: 342-17-106 N.89°56'30"W. 150.00' — ���----- 120.00' ------ 30.00'ti o 137 135 0 0 �'' 138 134---------- - - ``' APN:342-17-002 APN: 342-17-073 ' 30 DEDICATION FOR STREET � o PURPOSE o 0 o I (3,900.0 SFf) o o o' o 0 coil vi vi 120.00' _ _ _ 1 30 00' N.89° 6 30 W. 150.00'1 POB ' 1 U APN: 342-17-072 I APN: 342-17-082 i a i LEGEND: POB POINT OF BEGINNING 134 LOT NUMBER PER P-M-13 H ---- PROPERTY LINE CENTER LINE DEDICATION LINE O LAND S BASIS OF BEARINGS: ��, VtpN C�,p THE BEARING, NO°03'30"E, OF THE CENTER LINE OF SANTA LUCIA ROAD, AS SHOWN ON THAT CERTAIN MAP FILED IN THE OFFICE OF THE RECORDER OF SANTA CLARA COUNTY, * .12 31 21 STATE OF CALIFORNIA, IN BOOK 72 OF MAPS NO. L8235 AT PAGE 14, WAS USED AS THE BASIS OF sTj BEARINGS SHOWN ON THIS MAP. qTF OF CP��FC� EXHIBIT "B" DATE: NOV, 2020 PLAT TO ACCOMPANY LEGAL DESCRIPTION W E C 2625 MEDDLEFIELD RD #658 TEL: (650) 823-6466 DEDICATION FOR STREET PURPOSE SCALE: 1 "=50' & A S S O C 1 A T E S PALO ALTO, CA 94306 FAX: (650) 887-1294 10583 SANTA LUCIA ROAD, CUPERTINO, CA BY: EW Exhibit C SCHEDULE OF BONDS, FEES, AND DEPOSITS Street Improvement Category: PART A. Faithful Performance Bond: $50,000.00 PART B. Labor and Material Bond: $50,000.00 PART C. Checking and Inspection Fee: $3,554.00 PART D. Storm Drainage Fee: $1, 773.00 PART E. Street Tree Fee: EENE PART F. Map Checking Fee: $0.00 PART G. Park Fee: MR Page 11 of 11 Exhibit D Annual Premium $1,000.00 f CUPEQN0 Bond number- PR2720317 FAITHFUL PERFORMANCE AND COMPLETION IMPROVEMENT BOND KNOW ALL MEN BY THESE PRESENTS: That we,10583 Santa Lucia Investment LP as Principal and Platte River Insurance Company i as Surety are held_ and _firmly- bound - unto the City_ of - Cupertino, State of _ California, in the sum of Fift-Thousan and 00/00 _ Dollars ($ 50 000.00 ) we bind ourselves, our heirs, executors, successors, and assigns, jointly and severally, firmly by these presents. THE CONDITION of the foregoing obligation is such that, Z. WHEREAS, said Principal will perform all necessary improvements relative to fjuijffina�narmit numhPr RI_r)-202,0-1367 _ located At 1QS83.qanta I iicia Ava Cu inn rA 9501a in accordance with theapproved improvement plans prepared by Fri wu Civil Engineer on file in the Engineer's Office, City of Cupertino, and incorporated herein by reference. WHEREAS, improvements shall be completed within one (1) year from the date of acceptance of this bond by the City Council. WHEREAS, improvements shall be maintained for a period of at least one (1) year after acceptance of construction by the City. This bond shall be in full force and effect_through._the period of maintenance as provided in - - - - said contract. The maintenance period shall continue until such time that all deficiencies of construction are corrected to the satisfaction of the City Engineer's Office. WHEREAS, Principal and Surety shall be responsible for any and all damages arising under the original contract. NOW THEREFORE, if the said Principal shall well and truly do and perform all the covenants and obligations as set forth above, on its part to be done and performed at the time and in the manner specified therein, then this obligation shall be null and void, otherwise, this bond shall remain in full force and effect. In witness whereof, this instrument has been duly executed by the Principal and Surety this 15 day of December , 20.2Q_. (To be signed by Principal and Surety.. 10583 SantaLucia Inve tment LP Notary Acknowledgements required.) Principal Platte River Ins uran e Company Surety /� By:.r,Zan=l Chris Eley Attorney -in -Fact---' The above bond is accepted and approved this day of 20 SEE ATTACHED NotAR1AL CERTIFICATE 9 I1 1 l-,-` 2-C — 2/4/00 V Vvn t rUMV.7' PLATTE RIVER INSURANCE COMPANY POWER OF ATTORNEY PR2720317 Bond Number KNOW ALL MEN BY THESE PRESENTS, That the PLATTE RIVER INSURANCE COMPANY, a corporation of the State of Nebraska, having its principal offices in the City of Middleton, Wisconsin, does make, constitute and appoint CHRIS ELEY; AMELIA MCSHANE; JASON JENKIN its true and lawful Attomey(s)-in-fact, to make, execute, seal and deliver for and on its behalf, as surety, and as its act and deed, any and all bonds, undertakings and contracts of suretyship, provided that no bond or undertaking or contract of suretyship executed under this authority shall exceed in amount the sum of ------------------------------ALL WRITTEN INSTRUMENTS IN AN AMOUNT NOT TO EXCEED: $20,000,000.00 This Power of Attorney is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of PLATTE RIVER INSURANCE COMPANY at a meeting duly called and held on the 8th day of January, 2002. "RESOLVED, that the President, Executive Vice President, Vice President, Secretary or Treasurer, acting individually or otherwise, be and they hereby are granted the power and authorization to appoint by a Power of Attorney for the purposes only of executing and attesting bonds and undertakings, and other writings obligatory in the nature thereof, one or more resident vice-presidents, assistant secretaries and attomey(s)-in-Fact, each appointee to have the powers and duties usual to such offices to the business of this company; the signature of such officers and seal of the Company may be affixed to any such power of attorney or to any certificate relating thereto by facsimile, and any such power of attorney or certificate bearing such facsimile signatures or facsimile seal shall be valid and binding upon the Company, and any such power so executed and certified by facsimile signatures and facsimile seal shall be valid and binding upon the Company in the future with respect to any bond or undertaking or other writing obligatory in the nature thereof to which it is attached. Any such appointment may be revoked, for cause, or without cause, by any of said officers, at any time." In connection with obligations in favor of the Florida Department of Transportation only, it is agreed that the power and authority hereby given to the Attorney -in -Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations in favor of the Kentucky Department of Highways only, it is agreed that the power and authority hereby given to the Attomey-in- Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner — Department of Highways of the Commonwealth of Kentucky at least thirty (30) days prior to the modification or revocation. IN WITNESS WHEREOF, the PLATTE RIVER INSURANCE COMPANY has caused these presents to be signed by its officer undersigned and its corporate seal to be hereto affixed duly attested, this lst day of January, 2020. Attest: /1 ! PLATTE RIVER INSURANCE COMPANY (�`Xl\p1t1111111111111///j/�/�//////// Ryan J. Byrnes+ Senior Vice President, _ = John L. Sennett, Jr. Chief Financial Officer and Treasurer z ?SEAL = Chief Executive Officer and President Suzanne M. Broadbent ��4i���m/rnl'�IMIIf10`l�vpx Assistant Secretary STATE OF WISCONSIN COUNTY OF DANE S.S.: On the Ist day of January, 2020 before me personally came John L. Sennott, Jr., to me known, who being by me duly sworn, did depose and say: that he resides in the County of Hartford, State of Connecticut; that he is Chief Executive Officer and President of PLATTE RIVER INSURANCE COMPANY, the corporation described in and which executed the above instrument; that he knows the seal of the said corporation; that the seal affixed to said instrument is such corporate seal; that it was so affixed by order of the Board of Directors of said corporation and that he signed his name thereto by like order. J\` t\ts\nJREGF rlrmu„4jH�y �° 4� �. P, f0.. 3' � N David J. Regele STATE OF WISCONSIN _ Notary Public, Dane Co., WI nmmm COUNTY OF DANE S.S.: "h�,, �tto�°°� ` My Commission Is Permanent ma\ I, the undersigned, duly elected to the office stated below, now the incumbent in PLATTE RIVER INSURANCE COMPANY, a Nebraska Corporation, authorized to make this certificate, DO HEREBY CERTIFY that the foregoing attached Power of Attorney remains in full force and has not been revoked; and furthermore, that the Resolution of the Board of Directors, set forth in the Power of Attorney is now in force. Signed and scaled at the City of Middleton, State of Wisconsin this 15 day of December 20 20 �a�\`t\�g1tN11111n1In/ryN„ `' Andrew B. Diaz-Matos y' •��• \o`` Senior Vice President, General Counsel and Secretary ry�9j�hnnromau\ratt"� THIS DOCUMENT HAS BEEN GENERATED FOR A SPECIFIC BOND. IF YOU HAVE ANY QUESTIONS CONCERNING THE AUTHENTICITY OF THIS DOCUMENT CALL 800-475-4450. PR-ePOA-M (Rev. 01-2020) ACKNOWLEDGMENT STATE OF ARKANSAS ) )ss. COUNTY OF Saline ) BE IT REMEMBERED, on this day, personally appeared before me, _, known to me to be the person whose name is subscribed to the foregoing as attorney -in -fact, and acknowledged that he executed the same for the purposes therein contained. WITNESS my hand and official seal this 15' day of /]" ,,,,� 2020. 7 My Commission Expires: December 9, 2025 KIMBER.LY LYNETTE SOHL ' Arkansas • Saline County Notary Public • Comm. It 12696?66 My Commission Expires Dec 9. 2025 , (S E A L) ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validily of that document. State of California Santa Clara County of before meRitu Bhagra, NOTARY PUBLIC On ( 2-I I S 2- c "z✓ , (insert name and title of the officer) personally appeared ���� CA who proved to me it the st basisof and acknowledged toobe the me thatpersonks) whose ba/she/tbey executed the same in subscribed to the within instrument pis/her/tOretr authorized capacity(i*, and that by his/her/the signature* on the instrument the person(e, or the entity upon behalf of which the personKacted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. t � Signature (Seal) RITU BHAGRA `' COMM. #2294068 zz a �•� o Notary Public California O z " Santa Clara County j 9 M Comm. Expires June 20, 2021 EXHIBIT E CITY Or CUPE(�TINO Bond number: PR2720317 i LABOR AND MATERIAL BOND FOR SUBDIVISION IMPROVEMENTS Recitals 1. The City of Cupertino, California, and (hereinafter referred to as "Principal", have entered into an agreement whereby Principal agrees to instaII and complete certain designated ublic im rovements dated - - - -- P 1?Pr.Pmher 15 , 20 20 ,and identified as mprovernent Plans titled "New is incorporated by this reference as if set forth in full; and, Residence, 10583 Santa Lucia Road" 2. Pursuant to the agreement, Principal is required, before commencing performance of the work, to file a good and sufficient payment bond with the City of Cupertino to secure any claims brought under Title 15, Division 3, Part 4 of the Civil Code (commencing with Section 3082). NOW THEREFORE, the Principal and the undersigned as corporate surety (hereinafter referred to as "Surety") their heirs, successors, assigns, executors and administrators, jointly and severally are held bound unto the City of Cupertino and all contractors, subcontractors, laborers, materialmen and other persons employed in the performance of the agreement and referred in the aforementioned Civil Code in the sum of Eifty-Thousand and 00/00 _ dollars ($ 50,000.00 ), for materials furnished or labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect to such work or labor, that the surety will pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by the City of Cupertino in successfully enforcing such obligation, to be awarded and fixed by the court, and to be taxed as costs and to be included in the judgement therein rendered. It is hereby expressly stipulated and agreed that this bond shall inure to the benefit of any and all persons, companies and corporations entitled to file claims under Title I5 (commencing with Section 3082) of Part 4 of Division 3 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. Should the condition of this bond be fully performed, then this obligation shall become null and void, otherwise, it shall be and remain in full force and effect. The surety hereby stipulated and agrees that no change, extension of time, alteration or addition to the terms of said agreement or the specifications accompanying the same shall, in any manner, affect its obligations on this bond, and it does hereby waive notice of any such change, extension, alteration or addition. 2/4/00 IN WITNESS WHEREOF, this instrument has been duly executed by the Principal and Surety this 15 day of December , 202Q_. (To be signed by Principal and Surety Notary Acknowledgements required.) SEEATTACHED NOTARIAL CERTIFICATE Ulm 10583 Santa Luria loyestment LP Principal By: Platte River Insurance Company Surety By: G' Attorne n-Fact The above bond is hereby accepted and approved this day of CITY OF CUPERTINO 2/4/00 20 LOCK r-imS' PLATTE RIVER INSURANCE COMPANY PR2720317 POWER OF ATTORNEY Bond Number KNOW ALL MEN BY THESE PRESENTS, That the PLATTE RIVER INSURANCE COMPANY, a corporation of the State of Nebraska, having its principal offices in the City of Middleton, Wisconsin, does make, constitute and appoint CHRIS ELEY; AMELIA MCSHANE; JASON JENKINS-------------------------- ___------------------ its true and lawful Attorneys) -in -fact, to make, execute, seal and deliver for and on its behalf, as surety, and as its act and deed, any and all bonds, undertakings and contracts of suretyship, provided that no bond or undertaking or contract of suretyship executed under this authority shall exceed in amount the sum of ------------------------------ALL WRITTEN INSTRUMENTS IN AN AMOUNT NOT TO EXCEED: $20,000,000.00---------- -----_____-- This Power of Attorney is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of PLATTE RIVER INSURANCE COMPANY at a meeting duly called and held on the 8th day of January, 2002, "RESOLVED, that the President, Executive Vice President, Vice President, Secretary or Treasurer, acting individually or otherwise, be and they hereby are granted the power and authorization to appoint by a Power of Attorney for the purposes only of executing and attesting bonds and undertakings, and other writings obligatory in the nature thereof, one or more resident vice-presidents, assistant secretaries and attomey(s)-in-fact, each appointee to have the powers and duties usual to such offices to the business of this company; the signature of such officers and seal of the Company may be affixed to any such power of attorney or to any certificate relating thereto by facsimile, and any such power of attorney or certificate bearing such facsimile signatures or facsimile seal shall be valid and binding upon the Company, and any such power so executed and certified by facsimile signatures and facsimile seal shall be valid and binding upon the Company in the future with respect to any bond or undertaking or other writing obligatory in the nature thereof to which it is attached. Any such appointment may be revoked, for cause, or without cause, by any of said officers, at any time" In connection with obligations in favor of the Florida Department of Transportation only, it is agreed that the power and authority hereby given to the Attomey-in-Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations in favor of the Kentucky Department of Highways only, it is agreed that the power and authority hereby given to the Attorney -in - Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner — Department of Highways of the Commonwealth of Kentucky at least thirty (30) days prior to the modification or revocation. IN WITNESS WHEREOF, the PLATTE RIVER INSURANCE COMPANY has caused these presents to be signed by its officer undersigned and its corporate seal to be hereto affixed duly attested, this Ist day of January, 2020. Attest: Ryan J. Bymes ?r' Senior Vice President, Chief Financial Officer and Treasurer — ? SriL1L Suzanne M. Broadbent "Nitiprq�tt Assistant Secretary PLATTE RIVER INSURANCE COMPANY (:�� -� " t. John L. Sennott, Jr. Chief Executive Officer and President STATE OF WISCONSIN COUNTY OF DANE S.S.: On the I st day of January, 2020 before me personally came John L. Scnnott, Jr., to me known, who being by me duly swom, did depose and say: that he resides in the County of Hartford. State of Connecticut; that he is Chief Executive Officer and President of PLATTE RIVER INSURANCE COMPANY, the corporation described in and which executed the above instrument; that he knows the seal of the said corporation; that the seal affixed to said instrument is such corporate seal; that it was so affixed by order of the Board of Directors of said corporation and that he signed his name thereto by like order. \\\..`0J.RF- ,, 0PJ' , �c David J. Regele STATE OF WISCONSIN _sr Notary Public, Dane Co., Wl COUNTY OF DANE } S. �''y�o,,,or ~ ° `\ My Commission is Permanent MIrininitl I, the undersigned, duly elected to the office stated below, now the incumbent in PLATTE RIVER INSURANCE COMPANY, a Nebraska Corporation, authorized to make this certificate, DO HEREBY CERTIFY that the foregoing attached Power of Attorney remains in full force and has not been revoked; and furthermore, that the Resolution of the Board of Directors, set forth in the Power of Attorney is now in force. Signed and sealed at the City of Middleton, State of Wisconsin this 15 day of December , 20 20 -' \� Andrew B. Diaz-Matos Senior Vice President, General Counsel and Secretary THIS DOCUMENT HAS BEEN GENERATED FOR A SPECIFIC BOND. IF YOU HAVE ANY QUESTIONS CONCERNING THE AUTHENTICITY OF THIS DOCUMENT CALL 800-4754450. PR-ePOA-M (Rev. 01-2020) ACKNOWLEDGMENT STATE OF ARKANSAS ) )ss. COUNTY OF Saline ) BE IT REMEMBERED, on this day, personally appeared before me, C.�a " , known to me to be the person whose name is subscribed to the foregoing as attorney -in -fact, and acknowledged that he executed the same for the purposes therein contained. WITNESS my hand and official seal this % day of �, ' 12020. kJ-4,� • Publici My Commission Expires: December 9, 2025 r., KIMBERLY LYNETTE SGHL Arkansas - Saline County Notary Public - Comm. # 1269536E My Commission Expires Dec 9. 202, J. (SEAL) CALIFORNIA ALL-PURPOSE CERTIFICATE OF ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of On i before me, � � � , Notary Public, —T ere insert name and title of the officer) personally appeared I Y' Q w H S U — who proved to me on the basis of satisfactory evidence to be the person(aywhose name(s)ris/are subscribed to the within instrument and acknowledged to me that /she/xkey executed the same in him&/her/tom authorized capacity(io, and that by big/her/t_ir signature(�on the instrument the person(*, -or the entity upon behalf of which the person(Wacted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. RITU HAW WITNESS my hand and official seal. COMM. #2294068 z �°am�. Notary Public - California o (� zSanta Clara County l� J1 Comm,Ex ires June 20, 2023 Signature of Notary Public (Notary Seal) ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT (Title or description of attached document) (Title or description of attached document continued) Number of Pages Document Date (Additional information) CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) ❑ Corporate Officer (Title) ❑ Partner(s) ❑ Attorney -in -Fact ❑ Trustee(s) ❑ Other INSTRUCTIONS FOR COMPLETING THIS FORM Any acknowledgment completed in California must contain verbiage exactly as appears above in the notary section or a separate acknowledgment form must be properly completed and attached to that document. The only exception is if a document is to be recorded outside of California. In such instances, any alternative acknowledgment verbiage as may be printed on such a document so long as the verbiage does not require the notary to do something that is illegal for a notary in California (i.e. certifying the authorized capacity of the signer). Please check the document carefully for proper notarial wording and attach this form if required. • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. lie/she/they,— is /are ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection of document recording. • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seal impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on file with the office of the county clerk. Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document. 44- Indicate title or type of attached document, number of pages and date. Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). • Securely attach this document to the signed document C 2004-2015 ProLink Signing Service, Inc. - Ai Rights Reserved vnvw.TheProlinkcont - Nationwide Notary Service CALIFORNIA ALL-PURPOSE CERTIFICATE OF ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Santa Clara On March 18, 2021 before me, Lauren Sapudar (Here insert name and title of the officer). personally appeared Roger Lee Notary Public, who proved to me on the basis of satisfactory evidence to be th pers (s) whose a ei /are subscribed to the within instrument and acknowledged to me that ifi�lshe/they executed the same in(D/her/their authorized ca ' (ies), and that b3t7s/her/their 4 (s) on the instrument theqers s), or the entity upon behalf of which the sus) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. 71,, Smyhand and official seal. Igna e of Notary PuTblic amy LAURENSAPUDAR Notary Public - CaliforniaSanta Clara County > Commission q 2247155 (Notary Seal) Comm. Expires Jun 22, 2022 ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT (Title or description of attached document) (Title or description of attached document continued) Number of Pages Document Date (Additional information) CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) ❑ Corporate Officer (Title) ❑ Partner(s) ❑ Attorney -in -Fact ❑ Trustee(s) ❑ Other INSTRUCTIONS FOR COMPLETING THIS FORM Any acknowledgment completed in California must contain verbiage exactly as appears above in the notary section or a separate acknowledgment form must be properly completed and attached to that document. The only exception is if a document is to be recorded outside of California. In such instances, any alternative acknowledgment verbiage as may be printed on such a document so long as the verbiage does not require the notary to do something that is illegal for a notary in California (i.e. certifying the authorized capacity of the signer). Please check the document carefully for proper notarial wording and attach this form if required. • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. he/she/Eke),— is /are ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection of document recording. • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seal impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on file with the office of the county clerk. Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document. Indicate title or type of attached document, number of pages and date. Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). • Securely attach this document to the signed document C 2004-2015 ProLink Signing Service, Inc. — All Rights Reserved www.TheProLink.com — Nationwide Notary Service